Authorize continuing engineering services with Metric Engineering

055, Florida Statutes, the Consultants' Competitive Negotiation Act, and has selected Consultant to perform the services hereunder. C. Consultant is experienced in providing professional services set forth in Exhibit A, Scope of Services, for traffic, roadway, and civil engineering projects. D. County desires to engage Consultant to provide continuing engineering services for traffic, roadway, and civil engineering projects. E. Negotiations pertaining to these services were undertaken between County and Consultant, and this Agreement incorporates the results of such negotiations.

1. 4.1.2 After complete execution of a Work Authorization under this Agreement, Contract Administrator will issue a Notice to Proceed for that authorized work. Consultant must not commence such work until receipt of a Notice to Proceed. 4.1.3 Any modifications to a Work Authorization will require an amended Work Authorization approved by Contract Administrator, County's Purchasing Director, or Board in accordance with the aggregate dollar limitations set forth above. Consultant's compensation will not exceed the amount approved in the Work Authorization unless such additional amount received the prior written approval from the appropriate authority. 4.1.4 All Work Authorizations must be delineated in the attached Exhibits D-1, D-2, or D-3, as applicable, or in a form substantially similar, and must contain, at a minimum, the following information and requirements: 4.1.4.1 A description of the work to be undertaken (which description must specify in detail the individual tasks and other activities to be performed by Consultant), a reference to this Agreement under which the work to be undertaken is authorized, and a statement of the method of compensation. 4.1.4.2 A budget establishing the amount of compensation, which amount will constitute a guaranteed maximum and must not be exceeded unless prior written approval of County is obtained. If County does not approve an increase in the guaranteed maximum amount, and the need for such action is not the fault of Consultant, the authorization will be terminated, and Consultant will be paid in full for all work completed to that point, but said amount will in no case exceed the guaranteed maximum amount. The information contained in the budget shall be in sufficient detail to identify the various elements of costs. 4.1.4.3 A time established for completion of the Services undertaken by Consultant or for the submission to County of documents, reports, and other information under this Agreement. BCF #202_CS (Rev. 07.01.2018) RFP Contract #PNC2119168P1 Page 4 of 109 4.1.4.4 Any other additional instructions or provision relating to the work authorized under this Agreement. 4.1.4.5 Work Authorizations must be dated, serially numbered, and signed. ARTICLE 5. TIME FOR PERFORMANCE; CONTRACTOR DAMAGES; LIQUIDATED DAMAGES 5.1 The initial term of this Agreement is for a period of three (3) years starting from the Effective Date and ending at 11:59 p.m. on the day preceding the third anniversary of that date (the "Initial Term"). Beyond the Initial Term, County shall have the option, through County's Purchasing Director, to renew this Agreement, under the same terms and conditions, for up to two (2) consecutive one (1) year terms; County's Purchasing Director may exercise this renewal option by sending notice of renewal to Consultant at least thirty (30) days prior to the expiration of the then-current term. Any renewal by County's Purchasing Director shall not result in a substantive change to the Agreement's terms. Consultant shall perform the Services within the time periods specified in the Work Authorization commencing from the date of the applicable Notice to Proceed. 5.2 Consultant must receive a Notice to Proceed from the Contract Administrator prior to commencement of Services or any phase thereof under this Agreement and any operative Work Authorization. Prior to granting approval for Consultant to proceed to any phase, the Contract Administrator may, at his or her sole option, require Consultant to submit the itemized deliverables and documents identified in the Work Authorization for the Contract Administrator's review. 5.3 If Consultant is unable to complete the Services under any Work Authorization because of delays resulting from untimely review by County or other governmental agencies having jurisdiction over a project and such delays are not the fault of Consultant, or because of delays caused by factors outside the control of Consultant, County shall grant a reasonable extension of time for completion of the Services and shall provide reasonable compensation, if appropriate. It shall be the responsibility of Consultant to notify the Contract Administrator promptly in writing whenever a delay in approval by a governmental agency is anticipated or experienced, and to inform the Contract Administrator of all facts and details related to the delay. 5.4 For any construction phase services authorized by a Work Authorization, if (a) Contractor fails to substantially complete a project on or before the substantial completion date specified in its agreement with County, or (b) if Contractor is granted an extension of time beyond said substantial completion date and Consultant's Services are extended beyond the substantial completion date through no fault of Consultant, then Consultant shall be compensated in accordance with Article 6 for all Services rendered by Consultant beyond the substantial completion date. 5.5 If Contractor fails to substantially complete a project on or before the substantial completion date specified in its agreement with County, and the failure to substantially complete BCF #202 __ cs (Rev. 07 01 2018) RFP Contract #PNC2119168P1 Page 5 of 109 is caused in whole or in part by Consultant, then Consultant shall pay to County its proportional share of any claim for damages to Contractor arising out of the delay. The provisions for the computation of delay costs, damages, or any other amounts, whether direct or indirect, in the agreement between the Contractor and County are incorporated herein. This section shall not affect the indemnification rights or obligations of either party otherwise set forth in this Agreement. 5.6 If Consultant is performing Services under a Work Authorization scheduled to be completed after the expiration of this Agreement, Consultant agrees to continue those Services until completion under the same terms and conditions as stated in the existing Work Authorization. ARTICLE 6. COMPENSATION AND METHOD OF PAYMENT 6.1 Amount and Method of Compensation. The total annual cumulative amount authorized for all non-Surtax Project Work Authorizations issued under this Agreement shall not exceed One Million Dollars ($1,000,000). When Surtax Project funding is also utilized for Work Authorizations, the total annual amount for all Work Authorizations may be increased but shall not exceed Three Million Dollars ($3,000,000). The method of compensation to be paid under each individual Work Authorization will be under one or a combination of the following methods as specified in the operative Work Authorization and based upon the Salary Costs described in Exhibit B. 6.1.1 Maximum Amount Not-To-Exceed Compensation. For Services identified in the Work Authorization as payable on a "Maximum Amount Not-To-Exceed" basis, compensation to Consultant shall be based upon the Salary Costs as described in Exhibit B up to a maximum not-to-exceed amount specified in the Work Authorization. 6.1.2 Lump Sum Compensation. For Services identified in the Work Authorization as payable on a "Lump Sum" basis, compensation to Consultant shall not be more than the total lump sum specified in the Work Authorization. 6.1.3 Optional Services. County may procure Optional Services up to a maximum not- to-exceed amount specified in the Work Authorization and in accordance with Article 7. Unused amounts of these Optional Services monies shall be retained by County. 6.1.4 Reimbursable Expenses. County will reimburse authorized Reimbursable Expenses as defined in

3 up to the maximum not-to-exceed amount specified in the Work Authorization. Unused amounts of those monies shall be retained by County. 6.1.5 Salary Costs. The maximum billing rates payable by County for each of Consultant's employee categories are shown on Exhibit B and are further described in

2. 6.1.6 Subconsultant Fees. Consultant shall bill Subconsultant fees using the employee categories for Salary Costs on Exhibit B as defined in

2 and Reimbursable Expenses defined in

3. Consultant shall bill Subconsultant fees with no mark-up and within any applicable maximum not to exceed amount. BCF #202_CS (Rev. 07.01.2018) RFP Contract #PNC2119168P1 Page 6 of 109 6.1. 7 Phased Payments. Payments for Services shall be paid out in accordance with the project's phasing specified in the Work Authorization and shall not exceed the amount set forth in the Work Authorization. The invoiced fee amount for each phase will be subject to retainage as set forth in

5. 6.2 Salary Costs. The term Salary Costs as used herein means the hourly rate actually paid to all personnel engaged directly on tasks under a Work Authorization issued under this Agreement, as adjusted by an overall multiplier that consists of the following: 1) a fringe benefits factor; 2) an overhead factor; and 3) an operating margin. Said Salary Costs are to be used only for time directly attributable to those tasks. The fringe benefit and overhead rates shall be Consultant's most recent and actual rates determined in accordance with Federal Acquisition Regulation ( 11FAR") guidelines and audited by an independent Certified Public Accountant. For the purposes of this Agreement, the rates must be audited for fiscal periods of Consultant within eighteen (18) months preceding the execution date of this Agreement. These rates shall remain in effect for the term of this Agreement except as provided for in this

2 inclusive of the subsections below. 6.2.1 Consultant shall require all of its Subconsultants to comply with the requirements of

2. 6.2.2 Salary Costs for Consultant and Subconsultants as shown in Exhibit B are the Maximum Billing Rates, which are provisional, subject to audit of actual costs, and if the audit discloses that the actual costs are less than the costs set forth on Exhibit B for Consultant or any Subconsultant, Consultant shall reimburse County based upon the actual costs determined by the audit. County may withhold the amount Consultant is required to reimburse County from any payment due Consultant. 6.2.3 Unless otherwise noted, the Salary Costs stated above are based upon Consultant's 11home office" rates. Should it become appropriate during the course of this Agreement that a "field office" rate be applied, then it is incumbent upon Consultant to submit a supplemental Exhibit B reflective of such rates for approval by Contract Administrator and, upon such County approval, invoice County accordingly. 6.2.4 The total hours payable by County for any "exempt" or 11nonexempt" personnel shall not exceed forty (40) hours per employee in any week. If the work requires Consultant's or Subconsultant's personnel to work in excess of forty (40) hours per week, any additional hours must be authorized in advance, in writing, by the Contract Administrator. If approved, Salary Costs for additional hours of service provided by nonexempt (hourly) employees or exempt (salaried) employees shall be invoiced at no more than one and one-half of the employee's hourly rate and in a manner consistent with Consultant's or Subconsultant's applicable certified FAR audit and all other provisions of

2. If a "Safe Harbor" rate is elected for use by Consultant or Subconsultant, then the additional hours are payable at no more than the employee's regular rate. BCF #202_CS (Rev 07.01.2018) RFP Contract #PNC2119168P1 Page 7 of 109 6.3 6.4 6.2.5 Consultant and any of its Subconsultants may alternatively use a "Safe Harbor" combined fringe benefit and overhead rate of 110% in lieu of providing fringe benefit and overhead cost factors certified by an independent Certified Public Accountant in accordance with the FAR guidelines. The Safe Harbor rate, once elected, shall remain in place for the entire term of this Agreement, and be applicable for use as "home" and "field" fringe benefit and overhead rates, if applicable, and shall not be subject to audit under this Agreement. All other provisions of

2 remain in place. 6.2.6 The maximum hourly rates shown in Exhibit B are subject to change annually beginning on the first anniversary of the Effective Date, and for each year of this Agreement thereafter. Consultant may submit a written request for change of maximum hourly rates to Contract Administrator thirty {30} days in advance of each annual anniversary date and such request will be subject to approval by Contract Administrator. Any increase in maximum hourly rates will be limited to the lesser of the change in cost of living or three percent {3%}. The increase in the cost of living shall be based on the Consumer Price Index {CPI) and shall be calculated as follows: the difference of the CPI for the current period, less the CPI for the previous period, divided by the CPI for the previous period, multiplied by 100. The CPI for the current period means the most recently published monthly index preceding the then-current anniversary date of this Agreement. The CPI for the previous period means the CPI for the same month of the prior year. All CPI indices must be obtained from the U.S. Department of Labor Table for Consumer Price Index - All Urban Consumers (Series ID CUURA320SA0} for the areas of Miami- Fort Lauderdale, FL {All Items), with a based period of 1982-84=100. If there is no change in the CPI, there shall not be an increase in the rate. Any changes to the hourly rates must be set forth on an amended Exhibit B executed by Contract Administrator and the Consultant. Reimbursable Expenses. For reimbursement of any travel costs, travel-related expenses, or other direct non-salary expenses directly attributable to any Work Authorization permitted under this Agreement, Consultant agrees to adhere to

061, Florida Statutes, except to the extent otherwise stated herein. County shall not be liable for any such expenses that have not been approved in writing in advance by the Contract Administrator. Reimbursable Subconsultant expenses must also comply with the requirements of this section. 6.3.1 For reimbursement of any Direct Expense Cost, Consultant shall use the applicable direct expense rate identified in Exhibit B. The direct expense rate shall remain in place for the entire term of this Agreement and any applicable Work Authorization. If any Subconsultants elect to use the direct expense rate, it shall be in accordance with the foregoing. County shall not be liable for any Direct Expense Cost that has not been approved in advance and in writing, by the Contract Administrator. Method of Billing. 6.4.1 For Maximum Amount Not-To-Exceed Compensation under

1.1. Consultant shall submit billings that are identified by the specific project number on a BCF #202_CS (Rev. 07 01 2018) RFP Contract #PNC2119168P1 Page 8 of 109 6.5 monthly basis in a timely manner for all Salary Costs and Reimbursable Expenses attributable to the Work Authorization. These billings shall identify the nature of the work performed, the total hours of work performed, and the employee category of the individuals performing same. Billings shall itemize and summarize Reimbursable Expenses by category and identify the personnel incurring the expense and the nature of the work with which such expense was associated. Where prior written approval by Contract Administrator is required for Reimbursable Expenses, a copy of said approval shall accompany the billing for such reimbursable. Billings shall also indicate the cumulative amount of CBE participation to date. The statement shall show a summary of Salary Costs and Reimbursable Expenses with accrual of the total and credits for portions paid previously. External Reimbursable Expenses and Subconsultant fees must be documented by copies of invoices or receipts that describe the nature of the expenses and contain a project number or other identifier that clearly indicates the expense is identifiable to the Services authorized by the operative Work Authorization. Subsequent addition of the identifier to the invoice or receipt by Consultant is not acceptable except for meals and travel expenses. Internal expenses must be documented by appropriate Consultant's cost accounting forms with a summary of charges by category. When requested, Consultant shall provide backup for past and current invoices that records hours and Salary Costs by employee category, Reimbursable Expenses by category, and Subconsultant fees on a task basis, so that total hours and costs by task may be determined. 6.4.2 For Lump Sum Compensation under

1.2. Consultant shall submit billings that are identified by the specific project number on a monthly basis in a timely manner. These billings shall identify the nature of the work performed, the phase of work, and the estimated percent of work accomplished. Billings for each phase shall not exceed the amounts allocated to said phase. Billings shall also indicate the cumulative amount of CBE participation to date. The statement shall show a summary of fees with accrual of the total and credits for portions paid previously. When requested, Consultant shall provide backup for past and current invoices that record hours, salary costs, and expense costs on a task basis, so that total hours and costs by task may be determined. Payment Procedure. 6.5.1 County shall pay Consultant within thirty {30) days after receipt of Consultant's proper invoice, as defined by County's Prompt Payment Ordinance, minus any applicable retainage or other deductions permitted by this Agreement. 6.5.2 Unless otherwise provided in this section, retainage in the amount of ten percent {10%) of each invoice shall be retained by County until satisfactory completion of the applicable phase. When the Services to be performed on all phases under a Work Authorization are fifty percent {50%) complete, upon written request by Consultant and written approval by the Contract Administrator that the Services are progressing in a satisfactory manner, the Contract Administrator, in his or her sole discretion, may authorize the reduction of retainage to five percent {5%) of each invoice for subsequent BCF #202_CS (Rev 07 012018) RFP Contract #PNC2119168P1 Page 9 of 109 payments. No amount shall be withheld from payments for Reimbursable Expenses or for Services performed during the construction phase. 6.5.3 Upon Consultant's completion of each phase to the satisfaction of the Contract Administrator, County shall remit to Consultant any amounts withheld as retainage for that phase. Final payment under each Work Authorization must be approved by the Purchasing Director. 6.5.4 Payment will be made to Consultant at the following address: Metric Engineering, Inc. 13940 S.W. 136 Street, Suite 200 Miami, Florida 33186 6.6 Fiscal Year. The continuation of this Agreement beyond the end of any County fiscal year is subject to both the appropriation and the availability of funds in accordance with Chapter 129, Florida Statutes. 6. 7 Consultant shall pay Subcons1:Jltants and suppliers providing Services under any Work Authorization issued in accordance with this Agreement within fifteen {15} days following receipt of payment from County for such subcontracted work or supplies. If Consultant withholds an amount as retainage from a Subconsultant or supplier, Consultant shall release such retainage and pay same within fifteen {15} days following receipt of payment of retained amounts from County. The Contract Administrator may, at its option, increase allowable retainage or withhold progress payments unless and until Consultant demonstrates timely payments of sums due to all Subconsultants and suppliers. Consultant shall include requirements substantially similar to those set forth in this section in its contracts with Subconsultants and suppliers. ARTICLE 7. OPTIONAL AND ADDITIONAL SERVICES; CHANGES IN SCOPE OF SERVICES 7.1 County or Consultant may request changes that would increase, decrease, or otherwise modify the Scope of Services to be provided under an operative Work Authorization. Unless otherwise expressly permitted herein, such changes must be made in accordance with the provisions of the Broward County Procurement Code and must be contained in a written amendment, executed by the Parties hereto, with the same formality and of equal dignity herewith. 7.2 Consultant may, in Contract Administrator's sole discretion, be authorized to perform Optional Services as described in Exhibit A, Scope of Services, and up to the maximum fee amount established in the operative Work Authorization for those Optional Services. Any Optional Services to be performe_d by Consultant under this Agreement must first be authorized by Contract Administrator in each Work Authorization and in accordance with Article 4 and must not exceed the cumulative amount authorized in the Work Authorization for those Optional Services. A Work Authorization for Optional Services shall specify the method of compensation applicable to that Work Authorization and the required completion date for those Optional Services. BCF #202_CS (Rev. 07 01 .2018) RFP Contract #PNC2119168P1 Page 10 of 109 7.3 If a dispute between the Contract Administrator and Consultant arises over whether any work requested by County is within the scope of contracted Services and such dispute cannot be resolved by the Contract Administrator and Consultant, such dispute shall be promptly presented to Purchasing Director for resolution, whose decision shall be in writing and shall be final and binding on the Parties. During the pendency of any dispute, Consultant shall promptly perform the disputed work. ARTICLE 8. REPRESENTATIONS AND WARRANTIES 8.1 Representation of Authority. Consultant represents and warrants that this Agreement constitutes the legal, valid, binding, and enforceable obligation of Consultant, and that neither the execution nor performance of this Agreement constitutes a breach of any agreement that Consultant has with any third party or violates any law, rule, regulation, or duty arising in law or equity applicable to Consultant. Consultant further represents and warrants that execution of this Agreement is within Consultant's legal powers, and each individual executing this Agreement on behalf of Consultant is duly authorized by all necessary and appropriate action to do so on behalf of Consultant and does so with full legal authority. 8.2 Solicitation Representations. Consultant represents and warrants that all statements and representations made in Consultant's proposal, bid, or other supporting documents submitted to County in connection with the solicitation, negotiation, or award of this Agreement, including during the procurement or evaluation process, were true and correct when made and are true and correct as of the date Consultant executes this Agreement, unless otherwise expressly disclosed in writing by Consultant. 8.3 Contingency Fee. Consultant represents that it has not paid or agreed to pay any person or entity, other than a bona fide employee working solely for Consultant, any fee, commission, percentage, gift, or other consideration contingent upon or resulting from the award or making of this Agreement. 8.4 Truth-In-Negotiation Representation. Consultant's compensation under this Agreement is based upon its representations to County, and Consultant certifies that the wage rates, factual unit costs, and other information supplied to substantiate Consultant's compensation, including, without limitation, in the negotiation of this Agreement, are accurate, complete, and current as of the date Consultant executes this Agreement. Consultant's compensation will be reduced to exclude any significant sums by which the contract price was increased due to inaccurate, incomplete, or noncurrent wage rates and other factual unit costs. 8.5 Public Entity Crime Act. Consultant represents that it is familiar with the requirements and prohibitions under the Public Entity Crime Act,

133, Florida Statutes, and represents that its entry into this Agreement will not violate that Act. Consultant further represents that there has been no determination that it committed a "public entity crime" as defined by

133, Florida Statutes, and that it has not been formally charged with committing an act defined as a "public entity crime" regardless of the amount of money involved or whether Consultant has been placed on the convicted vendor list. BCF #202_CS (Rev 07.01.2018) RFP Contract #PNC2119168P1 Page 11 of 109 8.6 Discriminatory Vendor and Scrutinized Companies Lists. Consultant represents that it has not been placed on the discriminatory vendor list as provided in

134, Florida Statutes. Consultant further represents that it is not ineligible to contract with County on any of the grounds stated in

135, Florida Statutes. 8.7 Warranty of Performance. Consultant represents and warrants that it possesses the knowledge, skill, experience, and financial capability required to perform and provide all required and optional Services under this Agreement, and that each person and entity that will provide Services under this Agreement is duly qualified to perform such services by all appropriate governmental authorities, where required, and is sufficiently experienced and skilled in the area(s) for which such person or entity will render Services. Consultant represents and warrants that the Services under this Agreement shall be performed in a skillful and respectful manner, and that the quality of all such services shall equal or exceed prevailing industry standards for the provision of such services. 8.8 Domestic Partnership Requirement. Unless this Agreement is exempt from the provisions of the Broward County Domestic Partnership Act, Section 16½-157, Broward County Code of Ordinances, Consultant certifies and represents that it will comply with the provisions of Section 16½-157 for the duration of this Agreement, and the contract language referenced in Section 16½-157 is deemed incorporated in this Agreement as though fully set forth in this section. 8.9 Breach of Representations. In entering into this Agreement, Consultant acknowledges that County is materially relying on the representations and warranties of Consultant stated in this article. County shall be entitled to recover any damages it incurs to the extent any such representation or warranty is untrue. In addition, if any such representation or warranty is false, County shall have the right, at its sole discretion, to terminate this Agreement without any further liability to Consultant, to deduct from the compensation due Consultant under this Agreement the full amount of any value paid in violation of a representation or warranty, or to recover all sums paid to Consultant under this Agreement. Furthermore, a false representation may result in debarment from County's competitive procurement activities. ARTICLE 9. TERMINATION 9.1 Termination. This Agreement or any Work Authorization issued under this Agreement may be terminated for cause by the aggrieved party if the party in breach has not corrected the breach within ten (10) days after receipt of written notice from the aggrieved party identifying the breach. This Agreement may also be terminated for convenience by the Board. Termination for convenience by the Board shall be effective on the termination date stated in written notice provided by County, which termination date shall be not less than thirty (30) days after the date of such written notice. If this Agreement or any Work Authorization was entered into on behalf of County by someone other than the Board, termination by County may be by action of the County Administrator or County representative (including his or her successor} who entered in this Agreement on behalf of County. This Agreement may also be terminated by the County Administrator upon such notice as the County Administrator deems appropriate BCF #202_CS (Rev. 07.01.2018) RFP Contract #PNC2119168P1 Page 12 of 109 under the circumstances if the County Administrator determines that termination is necessary to protect the public health, safety, or welfare. If County erroneously, improperly, or unjustifiably terminates for cause, such termination shall be deemed a termination for convenience and shall be effective thirty {30} days after such notice of termination for cause is provided. 9.2 This Agreement or any Work Authorization issued under this Agreement, may be terminated for cause by County for reasons including, but not limited to, any of the following: 9.2.1 Consultant's failure to suitably perform the work, failure to continuously perform the Services in a manner calculated to meet or accomplish the objectives in this Agreement or Work Authorization, or repeated {whether negligent or intentional} submission for payment of false or incorrect bills or invoices; 9.2.2 If Consultant is a "scrutinized company" pursuant to

473, Florida Statutes, if Consultant is placed on a "discriminatory vendor list" pursuant to

134, Florida Statutes, or if Consultant provides a false certification submitted pursuant to

135, Florida Statutes; 9.2.3 By the Contract Administrator or the Director of Office of Economic and Small Business Development {"OESBD"} for any fraud, misrepresentation, or material misstatement by Consultant in the award or performance of this Agreement or that otherwise violates any applicable requirement of Section 1-81, Broward County Code of Ordinances; or 9.2.4 By the Director of the OESBD upon the disqualification of Consultant as a CBE if Consultant's status as a CBE was a factor in the award of this Agreement and such status was misrepresented by Consultant, or upon the disqualification of one or more of Consultant's CBE participants by County's Director of the OESBD if any such participant's status as a CBE firm was a factor in the award of this Agreement and such status was misrepresented by Consultant during the procurement or the performance of this Agreement. 9.3 Notice of termination shall be provided in accordance with the "Notices" section of this Agreement except that notice of termination by the County Administrator to protect the public health, safety, or welfare may be oral notice that shall be promptly confirmed in writing. 9.4 If this Agreement or any Work Authorization issued under this Agreement is terminated for convenience, Consultant shall be paid for any Services properly performed under this Agreement or operative Work Authorization through the termination date specified in the written notice of termination, subject to any right of County to retain any sums otherwise due and payable. Consultant acknowledges and agrees that it has received good, valuable, and sufficient consideration from County, the receipt and adequacy of which are acknowledged by Consultant, for County's right to terminate this Agreement for convenience. BCF #202_CS (Rev 07.01 2018) RF'P Contract #PNC2119168P1 Page 13 of 109 9.5 If this Agreement or any Work Authorization is terminated, for any reason, any amounts due Consultant shall be withheld by County until Consultant has provided all documents required to be provided to County. ARTICLE 10. INSURANCE 10.1 For the duration of the Agreement, Consultant shall, at its sole expense, maintain the minimum insurance coverages stated in Exhibit C in accordance with the terms and conditions of this article. Consultant shall maintain insurance coverage against claims relating to any act or omission by Consultant, its agents, representatives, employees, or Subconsultants in connection with this Agreement. County reserves the right at any time to review and adjust the limits and types of coverage required under this article. 10.2 Consultant shall ensure that "Broward County" is listed and endorsed as an additional insured as stated in Exhibit Con all policies required under this article. 10.3 On or before the date this Agreement is fully executed or at least fifteen {15} days prior to commencement of Services, Consultant shall provide County with a copy of all Certificates of Insurance or other documentation sufficient to demonstrate the insurance coverage required in this article. If and to the extent requested by County, Consultant shall provide complete, certified copies of all required insurance policies and all required endorsements within thirty {30} days after County's request. 10.4 Consultant shall ensure that all insurance coverages required by this article shall remain in full force and effect for the duration of this Agreement and until all performance required by Consultant has been completed, as determined by Contract Administrator. Consultant or its insurer shall provide notice to County of any cancellation or modification of any required policy at least thirty {30) days prior to the effective date of cancellation or modification, and at least ten {10) days prior to the effective date of any cancellation due to nonpayment, and shall concurrently provide County with a copy of its updated Certificates of Insurance evidencing continuation of the required coverage(s). Consultant shall ensure that there is no lapse of coverage at any time during the time period for which coverage is required by this article. 10.5 Consultant shall ensure that all required insurance policies are issued by insurers: (1) assigned an A. M. Best rating of at least "A-" with a Financial Size Category of at least Class VII; (2) authorized to transact insurance in the State of Florida; or (3) a qualified eligible surplus lines insurer pursuant to

917 or 626.918, Florida Statutes, with approval by County's Risk Management Division. 10.6 If Consultant maintains broader coverage or higher limits than the minimum insurance requirements stated in Exhibit C, County shall be entitled to any such broader coverage and higher limits maintained by Consultant. All required insurance coverages under this article shall provide primary coverage and shall not require contribution from any County insurance, self- insurance or otherwise, which shall be in excess of and shall. not contribute to the insurance required and provided by Consultant. BCF #202_CS (Rev. 07.01.2018) RFP Contract #PNC2119168P1 Page 14 of 109 10.7 Consultant shall declare in writing any self-insured retentions or deductibles over the limit(s) prescribed in Exhibit C and submit to County for approval at least fifteen (15) days prior to the date this Agreement is fully executed or commencement of Services. Consultant shall be solely responsible for and shall pay any deductible or self-insured retention applicable to any claim against County. County may, at any time, require Consultant to purchase coverage with a lower retention or provide proof of ability to pay losses and related investigations, claim administration, and defense expenses within the retention. Consultant agrees that any deductible or self-insured retention may be satisfied by either the named insured or County, if so elected by County, and Consultant agrees to obtain same in endorsements to the required policies. 10.8 Unless prohibited by the applicable policy, Consultant waives any right to subrogation that any of Consultant's insurer may acquire against County, and agrees to obtain same in an endorsement of Consultant's insurance policies. 10.9 Consultant shall require that each Subconsultant maintains insurance coverage that adequately covers the Services provided by that Subconsultant on substantially the same insurance terms and conditions required of Consultant under this article. Consultant shall ensure that all such Subconsultants comply with these requirements and that "Broward County" is named as an additional insured under the Subconsultants' applicable insurance policies. 10.10 If Consultant or any Subconsultant fails to maintain the insurance required by this Agreement, County may pay any costs of premiums necessary to maintain the required coverage and deduct such costs from any payment otherwise due to Consultant. Consultant shall not permit any Subconsultant to provide Services under this Agreement unless and until the requirements of this article are satisfied. If requested by County, Consultant shall provide, within one (1) business day, evidence of each Subconsultant's compliance with this section. 10.11 If any of the policies required under this article provide claims-made coverage: (1) any retroactive date must be prior to the date this Agreement is fully executed; (2) the required coverage must be maintained after termination or expiration of the Agreement for at least the duration stated in Exhibit C, and (3) if coverage is canceled or nonrenewed and is not replaced with another claims-made policy form with a retroactive date prior to the date this Agreement is fully executed, Consultant must obtain and maintain "extended reporting" coverage that applies after termination or expiration of the Agreement for at least the duration stated in Exhibit C. ARTICLE 11. EQUAL EMPLOYMENT OPPORTUNITY AND CBE COMPLIANCE 11.1 No party to this Agreement may discriminate on the basis of race, color, sex, religion, national origin, disability, age, marital status, political affiliation, sexual orientation, pregnancy, or gender identity and e~pression in the performance of this Agreement. Consultant shall include the foregoing or similar language in its contracts with any Subconsultants, except that any project assisted by the U.S. Department ofTransportation funds shall comply with the nondiscrimination requirements in 49 C.F.R. Parts 23 and 26. 11.2 Consultant shall comply with all applicable requirements of Section 1-81, Broward County Code of Ordinances, in the award and administration of this Agreement. Failure by Consultant BCF #202_CS (Rev. 07.01.2018) RFP Contract #PNC2119168P1 Page 15 of 109 to carry out any of the requirements of this article shall constitute a material breach of this Agreement, which shall permit County to terminate this Agreement or exercise any other remedy provided under this Agreement, the Broward County Code of Ordinances, the Broward County Administrative Code, or under other applicable law, all such remedies being cumulative. 11.3 Consultant will meet the required CBE goal by utilizing the CBE firms listed in Exhibit E (or a CBE firm substituted for a listed firm, if permitted) for Twenty-Six percent (26%} of total Services under this Agreement (the "Commitment"). 11.4 In performing the Services, Consultant shall utilize the CBE firms listed in Exhibit E for the scope of work and the percentage of work amounts identified on each Letter of Intent. Promptly upon execution of this Agreement by County, Consultant shall enter into formal contracts with the CBE firms listed in Exhibit E and, upon request, shall provide copies of the contracts to the Contract Administrator and OESBD. 11.5 Each CBE firm utilized by Consultant to meet the CBE goal must be certified by OESBD. Consultant shall inform County immediately when a CBE firm is not able to perform or if Consultant believes the CBE firm should be replaced for any other reason, so that OESBD may review and verify the good faith efforts of Consultant to substitute the CBE firm with another CBE firm. Whenever a CBE firm is terminated for any reason, Consultant shall provide written notice to OESBD and, upon written approval ofthe Director of OESBD, shall substitute another CBE firm in order to meet the CBE goal, unless otherwise provided in this Agreement or agreed in writing by the Parties. Such substitution shall not be required if the termination results from modification of the Scope of Services and no CBE firm is available to perform the modified Scope of Services; in which event Consultant shall notify County, and OESBD may adjust the CBE goal by written notice to Consultant. Consultant shall not terminate a CBE firm for convenience without County's prior written consent, which consent shall not be unreasonably withheld. 11.6 The Parties stipulate that if Consultant fails to meet the Commitment, the damages to County arising from such failure are not readily ascertainable at the time of contracting. If Consultant fails to meet the Commitment and County determines, in the sole discretion of the OESBD Program Director, that Consultant failed to make Good Faith Efforts (as defined in Section 1-81, Broward County Code of Ordinances) to meet the Commitment, Consultant shall pay County liquidated damages in an amount equal to fifty percent (50%} of the actual dollar amount by which Consultant failed to achieve the Commitment, up to a maximum amount of ten percent (10%) of the total contract amount, excluding costs and reimbursable expenses. An example of this calculation is stated in Section 1-81.7, Broward County Code of Ordinances. As elected by County, such liquidated damages amount shall be either credited against any amounts due from County, or must be paid to County within thirty (30) days after written demand. These liquidated damages shall be County's sole contractual remedy for Consultant's breach of the Commitment, but shall not affect the availability of administrative remedies under Section 1-81. Any failure to meet the Commitment attributable solely to force majeure, changes to the scope of work by County, or inability to substitute a CBE Subconsultant w.here the OESBD Program Director has determined that such inability is due to no fault of Consultant, shall not be deemed a failure by Consultant to meet the Commitment. BCF #202_ CS (Rev. 07.01 2018) RFP Contract #PNC2119168P1 Page 16 of 1 09 11.7 Consultant acknowledges that the Board, acting through OESBD, may make minor administrative modifications to Section 1-81, Broward County Code of Ordinances, which shall become applicable to this Agreement if the administrative modifications are not unreasonable. Written notice of any such modification shall be provided to Consultant and shall include a deadline for Consultant to notify County in writing if Consultant concludes that the modification exceeds the authority under this section. Failure of Consultant to timely notify County of its conclusion that the modification exceeds such authority shall be deemed acceptance of the modification by Consultant. 11.8 County may modify the required participation of CBE firms under this Agreement in connection with any amendment, extension, modification, change order, or Work Authorization to this Agreement that, by itself or aggregated with previous amendments, extensions, modifications, change orders, or Work Authorizations, increases the initial Agreement price by ten percent (10%) or more. Consultant shall make a good faith effort to include CBE firms in work resulting from any such amendment, extension, modification, change order, or Work Authorization, and shall report such efforts, along with evidence thereof, to OESBD. 11.9 Consultant shall provide written monthly reports to the Contract Administrator attesting to Consultant's compliance with the CBE goal stated in this article. In addition, Consultant shall allow County to engage in onsite reviews to monitor Consultant's progress in achieving and maintaining Consultant's contractual and CBE obligations. The Contract Administrator in conjunction with OESBD shall perform such review and monitoring, unless otherwise determined by the County Administrator. 11.10 The presence of a "pay when paid" provision in a Consultant's contract with a CBE firm shall not preclude County or its representatives from inquiring into allegations of nonpayment or exercising any right under this Agreement. ARTICLE 12. MISCELLANEOUS 12.1 Contract Administrator Authority. The Contract Administrator is authorized to coordinate and communicate with Consultant to manage and supervise the performance of this Agreement. Unless expressly stated otherwise in this Agreement or otherwise set forth in an applicable provision of the Broward County Procurement Code, Broward County Code of Ordinances, or Broward County Administrative Code, the Contract Administrator may exercise any ministerial authority under this Agreement in connection with the day-to-day management of this Agreement provided that such instructions and determinations do not change the Scope of Services. The Contract Administrator may designate one or more County employees with authority pertaining to day-to-day project management or activities for each Work Authorization. Consultant shall notify Contract Administrator in writing of Consultant's representative(s) to whom matters involving the Work Authorization shall be addressed. 12.2 Rights in Documents and Work. Any and all reports, photographs, surveys, and documents created by Consultant in connection with performing Services under this Agreement or any Work Authorization shall be owned by County and shall be deemed works for hire by Consultant and its agents; if the Services are determined not to be a work for hire, Consultant hereby assigns all right, title, and interest, including any copyright or other intellectual property BCF #202_CS (Rev. 07.01 2018) RFP Contract #PNC2119168P1 Page 17 of 109 rights in or to the work, to County. In the event of termination of this Agreement, any reports, photographs, surveys, and other data and documents created by Consultant, whether finished or unfinished, shall become the property of County and shall be delivered by Consultant to the Contract Administrator within seven (7) days after termination of this Agreement. Any compensation due to Consultant may be withheld until all documents are received as provided in this Agreement. Consultant shall ensure that the requirements of this section are included in all agreements with its Subconsultant{s}. 12.3 Ownership of Documents. All finished or unfinished documents, data, studies, surveys, drawings, maps, models, photographs, specifications and reports prepared or provided by Consultant in connection with this Agreement shall become the property of County, whether the Work Authorization for which they are made is completed or not, and shall be delivered by Consultant to Contract Administrator within fifteen {15} days of the receipt of the written notice of termination. If applicable, County may withhold any payments then due to Consultant until Consultant complies with the provisions of this section. 12.4 Public Records. To the extent Consultant is acting on behalf of County as stated in

0701, Florida Statutes, Consultant shall: 12.4.1 Keep and maintain public records required by County to perform the services under this Agreement; 12.4.2 Upon request from County, provide County with a copy of the requested records or allow the records to be inspected or copied within a reasonable time and at a cost that does not exceed that provided in Chapter 119, Florida Statutes, or as otherwise provided by law; 12.4.3 Ensure that public records that are exempt or confidential and exempt from public record requirements are not disclosed except as authorized by law for the duration of this Agreement and following completion or termination of this Agreement if the records are not transferred to County; and 12.4.4 Upon completion or termination of this Agreement, transfer to County, at no cost, all public records in possession of Consultant or keep and maintain public records required by County to perform the services. If Consultant transfers the records to County, Consultant shall destroy any duplicate public records that are exempt or confidential and exempt. If Consultant keeps and maintains the public records, Consultant shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to County upon request in a format that is compatible with the information technology systems of County. A request for public records regarding this Agreement must be made directly to County, who will be responsible for responding to any such public records requests. Consultant will provide any requested records to County to enable County to respond to the public records request. Any material submitted to County that Consultant contends constitutes or contains trade secrets or is otherwise exempt from production under Florida public records laws {including Chapter 119, BCF #202_CS (Rev. 07 01 2018) RFP Contract #PNC2119168P1 Page 18 of 109 Florida Statutes} ("Trade Secret Materials"} must be separately submitted and conspicuously labeled "EXEMPT FROM PUBLIC RECORD PRODUCTION -TRADE SECRET." In addition, Consultant must, simultaneous with the submission of any Trade Secret Materials, provide a sworn affidavit from a person with personal knowledge attesting that the Trade Secret Materials constitute trade secrets under

081, Florida Statutes, and stating the factual basis for same. If a third party submits a request to County for records designated by Consultant as Trade Secret Materials, County shall refrain from disclosing the Trade Secret Materials, unless otherwise ordered by a court of competent jurisdiction or authorized in writing by Consultant. Consultant shall indemnify and defend County and its employees and agents from any and all claims, causes of action, losses, fines, penalties, damages, judgments, and liabilities of any kind, including attorneys' fees, litigation expenses, and court costs, relating to the nondisclosure of any Trade Secret Materials in response to a records request by a third party. IF CONSULTANT HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO CONSULTANT'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS AGREEMENT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT (954) 577-4566, rtornese@BROWARD.ORG, 1 N. UNIVERSITY DRIVE, SUITE B3200, PLANTATION, FLORIDA 33324. 12.5 Audit Rights and Retention of Records. Consultant shall preserve all Contract Records (as defined below} for a minimum period of three (3} years after expiration or termination of this Agreement, any Work Authorization, or until resolution of any audit findings, whichever is longer. Contract Records shall, upon reasonable notice, be open to County inspection and subject to audit and reproduction during normal business hours. County audits and inspections pursuant to this section may be performed by any County representative (including any outside representative engaged by County}. County may conduct audits or inspections at any time during the term of this Agreement and for a period of three (3) years after the expiration or termination of this Agreement (or longer if required by law}. County may, without limitation, verify information, payroll distribution, and amounts through interviews, written affirmations, and on- site inspection with Consultant's employees, Subconsultants, vendors, or other labor. Contract Records include any and all information, materials and data of every kind and character, including, without limitation, records, books, papers, documents, subscriptions, recordings, agreements, purchase orders, leases, contracts, commitments, arrangements, notes, daily diaries, drawings, receipts, vouchers, memoranda, and any and all other documents that pertain to rights, duties, obligations, or performance under this Agreement. Contract Records include hard copy and electronic records, written policies and procedures, time sheets, payroll records and registers, cancelled payroll checks, estimating work sheets, correspondence, invoices and related payment documentation, general ledgers, insurance rebates and dividends, and any other records pertaining to rights, duties, obligations or performance under this Agreement, whether by Consultant or Subconsultants. County shall have the right to audit, review, examine, inspect, analyze, and make copies of all Contract Records at a location within Broward County. Consultant hereby grants County the right to conduct such audit or review at Consultant's place of business, if deemed appropriate by BCF #202_CS (Rev 07.012018) RFP Contract #PNC2119168P1 Page 19 of 109 County, with seventy-two (72) hours' advance notice. Consultant agrees to provide adequate and appropriate work space. Consultant shall provide County with reasonable access to Consultant's facilities, and County shall be allowed to interview all current or former employees to discuss matters pertinent to the performance of this Agreement. Consultant shall, by written contract, require its Subconsultants to agree to the requirements and obligations of this section. Any incomplete or incorrect entry in such books, records, and accounts shall be a basis for County's disallowance and recovery of any payment upon such entry. If an audit or inspection in accordance with this section discloses overpricing or overcharges to County of any nature by Consultant or its Subconsultants in excess of five percent (5%} of the total contract billings reviewed by County, the reasonable actual cost of County's audit shall be reimbursed to County by Consultant in addition to making adjustments for the overcharges. Any adjustments or payments due as a result of such audit or inspection shall be made within thirty (30) days after presentation of County's findings to Consultant. 12.6 Subconsultants. Consultant shall utilize only the Subconsultants identified in Exhibit F, Schedule of Subconsultants, to provide the Services under this Agreement. Consultant shall obtain written approval of Contract Administrator prior to changing or modifying the Schedule of Subconsultants, which shall be automatically updated upon such written approval. Consultant shall bind in writing each and every approved Subconsultant to the terms stated in this Agreement, provided that this provision shall not, in and of itself, impose the insurance requirements set forth in Article 10 on Consultant's Subconsultants. 12.7 Assignment. Neither this Agreement nor any interest herein shall be assigned, transferred, or encumbered without the written consent of the other party. County shall have the right to terminate this Agreement, effective immediately, if there is an assignment, or attempted assignment, transfer, or encumbrance, of this Agreement or any right or interest herein by Consultant without County's written consent. 12.8 Indemnification of County. Consultant shall indemnify and hold harmless County, its officers and employees from liabilities, damages, losses, and costs, including, but not limited to, reasonable attorneys' fees, to the extent caused by the negligence, recklessness or intentionally wrongful conduct of Consultant or other persons employed or utilized by Consultant in the performance of this Agreement. The provisions of this section shall survive the expiration or earlier termination of this Agreement. To the extent considered necessary by Contract Administrator and County Attorney, any sums due Consultant under this Agreement may be retained by County until all of County's Claims subject to this indemnification obligation have been settled or otherwise resolved, and any amount withheld shall not be subject to payment of interest by County. 12.9 Prior Agreements Superseded. This document incorporates and includes all prior negotiations, correspondence, conversations, agreements, or understandings applicable to the matters contained herein; and the Parties agree that there are no commitments, agreements, or understandings concerning the subject matter of this Agreement that are not contained in this BCF #202_CS (Rev 07.01.2018) RFP Contract #PNC2119168P1 Page 20 of 109 document. Accordingly, the Parties agree that no deviation from the terms hereof shall be predicated upon any prior representations or agreements whether oral or written. 12.10 Amendments. No modification, amendment, or alteration in the terms or conditions contained herein shall be effective unless contained in a written document executed with the same formality and of equal dignity herewith. 12.11 Notices. In order for a notice to a party to be effective under this Agreement, notice must be sent via U.S. first-class mail, hand delivery, or commercial overnight delivery, each with a contemporaneous copy via e-mail, to the addresses listed below and shall be effective upon mailing or hand delivery (provided the contemporaneous email is also sent). The addresses for notice shall remain as set forth in this section unless and until changed by providing notice of such change in accordance with the provisions of this section. FOR COUNTY: Broward County Highway Construction and Engineering Division Attn: Michael Hammond, P.E. Contract Administrator Governmental Center, Box B300 1 N. Drive Plantation, Florida 33324 Email address: mhammond@broward.org FOR CONSULTANT: Metric Engineering, Inc. Attn: Dale W. Cody, P.E., PTOE Senior Vice President of Production 525 Technology Park, Suite 153 Lake Mary, Florida 32746 Email address: dale.cody@metriceng.com 12.12 Interpretation. The titles and headings contained in this Agreement are for reference purposes only and shall not in any way affect the meaning or interpretation of this Agreement. All personal pronouns used in this Agreement shall include the other gender, and the singular shall include the plural, and vice versa, unless the context otherwise requires. Terms such as "herein," "hereof," "hereunder," and "hereinafter" refer to this Agreement as a whole and not to any particular sentence, paragraph, or section where they appear, unless the context otherwise requires. Whenever reference is made to a section or article of this Agreement, such reference is to the section or article as a whole, including all of the subsections of such section, unless the reference is made to a particular subsection or subparagraph of such section or article. Any reference to "days" means calendar days, unless otherwise expressly stated. 12.13 Consultant's Staff. Consultant will provide the key staff identified in its proposal for each Work Authorization as long as said key staff are in Consultant's employment. Consultant will obtain prior written approval of Contract Administrator to change key staff. Consultant shall provide Contract Administrator with such information as necessary to determine the suitability BCF #202_CS (Rev 07 01.2018) RFP Contract#PNC2119168P1 Page 21 of 109 of proposed new key staff. Contract Administrator will be reasonable in evaluating key staff qualifications. If Contract Administrator desires to request removal of any of Consultant's staff, Contract Administrator shall first meet with Consultant and provide reasonable justification for said removal; upon such reasonable justification, Consultant shall use good faith efforts to remove or reassign the staff at issue. 12.14 Drug-Free Workplace. To the extent required under

31(a)(2}, Broward County Administrative Code, or

087, Florida Statutes, Consultant certifies that it has a drug- free workplace program and that it will maintain such drug-free workplace program for the duration of this Agreement. 12.15 Independent Contractor. Consultant is an independent contractor under this Agreement, and nothing in this Agreement shall constitute or create a partnership, joint venture, or any other relationship between the Parties. In providing Services under this Agreement, neither Consultant nor its agents shall act as officers, employees, or agents of County, except as authorized by the Contract Administrator for permitting, licensing, or other regulatory requirements. Consultant shall not have the right to bind County to any obligation not expressly undertaken by County under this Agreement. 12.16 Regulatory Capacity. Notwithstanding the fact that County is a political subdivision with certain regulatory authority, County's performance under this Agreement is as a party to this Agreement and in the capacity as owner. If County exercises its regulatory authority, the exercise of such authority and the enforcement of any rules, regulation, laws, and ordinances shall have occurred under County's regulatory authority as a governmental body separate and apart from this Agreement, and shall not be attributable in any manner to County as a party to this Agreement. 12.17 Sovereign Immunity. Except to the extent sovereign immunity may be deemed to be waived by entering into this Agreement, nothing herein is intended to serve as a waiver of sovereign immunity by County nor shall anything included herein be construed as consent by County to be sued by third parties in any matter arising out of this Agreement. County is a political subdivision as defined in

28, Florida Statutes, and shall be responsible for the negligent or wrongful acts or omissions of its employees pursuant to

28, Florida Statutes. 12.18 Third-Party Beneficiaries. Neither Consultant nor County intends to directly or substantially benefit a third party by this Agreement. Therefore, the Parties acknowledge that there are no third-party beneficiaries to this Agreement and that no third party shall be entitled to assert a right or claim against either of them based upon this Agreement. 12.19 Conflicts. Neither Consultant nor its employees shall have or hold any continuing or frequently recurring employment or contractual relationship that is substantially antagonistic or incompatible with Consultant's loyal and conscientious exercise of judgment and care related to its performance under this Agreement. During the term of this Agreement, none of Consultant's officers or employees shall serve as an expert witness against County in any legal or administrative proceeding in which he, she, or Consultant is not a party, unless compelled by court process. Further, such persons shall not give sworn testimony or issue a report or writing, BCF #202~CS (Rev 07.01.2018) RFP Contract #PNC2119168P1 Page 22 of 109 as an expression of his or her expert opinion that is adverse or prejudicial to the interests of County in connection with any such pending or threatened legal or administrative proceeding unless compelled by court process. The limitations of this section shall not preclude Consultant or any persons in any way from representing themselves, including giving expert testimony in support of such representation, in any action or in any administrative or legal proceeding. If Consultant is permitted under this Agreement to utilize Subconsultants to perform any Services required by this Agreement, Consultant shall require such Subconsultants, by written contract, to comply with the provisions of this section to the same extent as Consultant. 12.20 Materiality and Waiver of Breach. Each requirement, duty, and obligation set forth in this Agreement was bargained for at arm's-length and is agreed to by the Parties. Each requirement, duty, and obligation set forth in this Agreement is substantial and important to the formation of this Agreement, and each is, therefore, a material term of this Agreement. County's failure to enforce any provision of this Agreement shall not be deemed a waiver of such provision or modification of this Agreement. A waiver of any breach of a provision of this Agreement shall not be deemed a waiver of any subsequent breach and shall not be construed to be a modification of the terms of this Agreement. To be effective, any waiver must be in writing signed by an authorized signatory of the waiving party. 12.21 Compliance with Laws. Consultant and the Services must comply with all applicable federal, state, and local laws, codes, ordinances, rules, and regulations including, without limitation, American with Disabilities Act, 42 U.S.C. § 12101, Section 504 of the Rehabilitation Act of 1973, and any related federal, state, or local laws, rules, and regulations. 12.22 Severability. If any part of this Agreement is found to be unenforceable by any court of competent jurisdiction, that part shall be deemed severed from this Agreement and the balance of this Agreement shall remain in full force and effect. 12.23 Joint Preparation. This Agreement has been jointly prepared by the Parties, and shall not be construed more strictly against either party. 12.24 Priority of Provisions. If there is a conflict or inconsistency between any term, statement, requirement, or provision of any document or exhibit attached to, referenced by, or incorporated in this Agreement and any provision of Articles 1 through 12 of this Agreement, the provisions contained in Articles 1 through 12 shall prevail and be given effect. 12.25 Law, Jurisdiction, Venue, Waiver of Jury Trial. This Agreement shall be interpreted and construed in accordance with and governed by the laws of the State of Florida. The exclusive venue for any lawsuitarising from, related to, or in connection with this Agreement shall be in the state courts of the Seventeenth Judicial Circuit in and for Broward County, Florida. If any claim arising from, related to, or in connection with this Agreement must be litigated in federal court, the exclusive venue for any such lawsuit shall be in the United States District Court or United States Bankruptcy Court for the Southern District of Florida. BY ENTERING INTO THIS AGREEMENT, CONSULTANT AND COUNTY HEREBY EXPRESSLY WAIVE ANY RIGHTS EITHER PARTY MAY HAVE TO A TRIAL BY JURY OF ANY CIVIL LITIGATION RELATED TO THIS AG REEM ENT. IF A PARTY FAILS TO WITHDRAW A REQUEST FOR A JURY TRIAL IN A LAWSUIT ARISING OUT OF THIS AGREEMENT AFTER WRITTEN NOTICE BY THE OTHER PARTY OF VIOLATION OF THIS BCF #202_CS (Rev. 07.01.2018) RFP Contract #PNC2119168P1 Page 23 of 109 SECTION, THE PARTY MAKING THE REQUEST FOR JURY TRIAL SHALL BE LIABLE FOR THE REASONABLE ATTORNEYS' FEES AND COSTS OF THE OTHER PARTY IN CONTESTING THE REQUEST FOR JURY TRIAL, AND SUCH AMOUNTS SHALL BE AWARDED BY THE COURT IN ADJUDICATING THE MOTION. 12.26 Reuse of Deliverables. County may, at its option, reuse (in whole or in part) the resulting end-product or deliverables resulting from Consultant's Services (including, but not limited to, drawings, specifications, other documents, and services as described herein and in Exhibit A or any Work Authorizations); and Consultant agrees to such reuse in accordance with this provision. If the Contract Administrator elects to reuse the services, drawings, specifications, and other documents, in whole or in part, prepared for any services rendered under this Agreement for other projects on other sites, Consultant will be paid a reuse fee to be negotiated between Consultant and County, subject to approval by the proper awarding authority. Each reuse shall include all Services and modifications to the drawings, specifications, and other documents normally required to adapt the design documents to a new site. This reuse may include preparation of reverse plans, changes to the program, provision for exceptional site conditions, preparation of documents for off-site improvements, provisions for revised solar orientation, provisions for revised vehicular and pedestrian access, and modifications to building elevations, ornament, or other aesthetic features. In all reuse assignments, the design documents shall be revised to comply with building codes and other jurisdictional requirements current at the time of reuse for the new site location. The terms and conditions of this Agreement shall remain in force for each reuse project, unless otherwise agreed by the Parties in writing. 12.27 Payable Interest. 12.27.1 Payment of Interest. County shall not be liable to pay any interest to Consultant for any reason, whether as prejudgment interest or for any other purpose, and in furtherance thereof Consultant waives, rejects, disclaims, and surrenders any and all entitlement it has or may have to receive interest in connection with a dispute or claim arising from, related to, or in connection with this Agreement. This subsection shall not apply to any claim for interest, including for post-judgment interest, if such application would be contrary to applicable law. 12.27.2 Rate of Interest. If the preceding subsection is inapplicable or is determined to be invalid or unenforceable by a court of competent jurisdiction, the annual rate of interest payable by County under this Agreement, whether as prejudgment interest or for any other purpose, shall be, to the full extent permissible under applicable law, one quarter of one percent (0.25%} simple interest (uncompounded). 12.28 Incorporation by Reference. Any and all Recital clauses stated above are true and correct and are incorporated in this Agreement by reference. The attached Exhibits are incorporated into and made a part of this Agreement. 12.29 Counterparts and Multiple Originals. This Agreement may be executed in multiple originals, and may be executed in counterparts, each of which shall be deemed to be an original, but all of which, taken together, shall constitute one and the same agreement. BCF #202_CS (Rev. 07.01 2018) RFP Contract #PNC2119168P 1 Page 24 of 109 12.30 Public Art and Design. To the extent any Work Authorization includes artwork as defined by Section 1-88, Broward County Code of Ordinances, Consultant shall cooperate with the artist for the purpose of properly incorporating the artist's design(s) into the design for a project. Consultant shall notify the artist in writing of all design meetings and shall provide the artist with a schedule of milestone dates. If requested by County, Consultant shall provide work space for the artist during the preliminary design and design phases. The artist's design as properly incorporated into the design for a project shall be permitted as part of the master site or facility plan. Consultant's compensation under this Agreement includes the services to comply with the requirements set forth in this section. Consultant shall ensure that Subconsultants, if any, are informed of Broward County's Public Art and Design Program and any applicable requirement of working with the artist(s). (The remainder of this page is intentionally left blank.) BCF #202_CS (Rev. 07 012018) RFP Contract #PNC2119168P1 Page 25 of 109 IN WITNESS WHEREOF, the Parties hereto have made and executed this Agreement: BROWARD COUNTY, through its BOARD OF COUNTY COMMISSIONERS, signing by and through its Mayor or Vice-Mayor authorized to execute same by Board action on the d,. 0-\}'\ day otQd::c:k/ 20 ')_('.) and CONSULTANT, signing by and through its ~ -1(€5\~ duly authorized to execute same. ATTEST: I / Browa r. County Admini ator, as 'r'0 ex offi ·o Clerk of the Broward County Board of County Commissioners MJK/hb BCF 202 07/ 01/2018 BCF #202_CS (Rev. 07 01.2018) RFP Contract #PNC2119168P1 COUNTY BROWARD COUNTY, by and through its Bo f County Commissioners By :,,,_ : ~~g~~=-:::::.::~::::::12~- L.-/ ~ ayofo~ 2rf2-0 Approved as to form by Andrew J. Meyers Broward County Attorney Governmental Center, Suite 423 115 South Andrews Avenue Fort Lauderdale, Florida 33301 Telephone: (954) 357-7600 Telecopier: (954) 357-7641 GAVIN Gavin Rynard Assistant County Attorney MICHAEL · Digitally signed by MICHAEL KERR By: KERR Michael J. Kerr Deputy County Attorney 9-11-20 (Date) 9-11-20 (Date) Page 26 of 109 AGREEMENT BETWEEN BROWARD COUNTY AND METRIC ENGINEERING, INC. FOR CONSULTANT SERVICES FOR CONTINUING ENGINEERING SERVICES FOR TRAFFIC, ROADWAY, AND CIVIL PROJECTS (RFP # PNC2119168Pl} FOR INDIVIDUAL: TWO WITNESSES HERE: Signature Print/Type Name Signature Print/Type Name FOR CORPORATION: ATTEST: ~/··· "~ .... ' •. ~,¾L}i) \ .. ···.~-~---·.'-/--i,____.,....._..,"""'"".......,'-"""'""" Secretary Mariley Perez (Typed Name of Secretary) TWO WITNESSES HERE: CONSULTANT By _____________ _ (Please Type Name) __ day of ______ ~ 20 __ _ OR DIGITAL CORPORATE SEAL HERE: Metric Engineering, Inc. (Typed Name of Consultant/Firm) D I W C d~ f; Digitally signed by Dale W Cody a e O ate: 2020.09.08 12:03:27 By ~o· President/Vice President Dale W. Cody, P.E., SVP (Typed Name and Title) ~ day of September OR DIGITAL CORPORATE SEAL HERE: Heidi Bouthillie-1,~~~:~\:iies;gned by Heidi . r-c5aie, 2020.09.08 12:09:51 .04·00· Signature Heidi Bouthillier Print/Type Name M I• d S 't~ Digitally signed by Melinda Smith e 1n a m1 1\iate: 202009.08 1244:00 -:ctii'llo· t; Signature Melinda Smith Print/Type Name BCF #202_CS (Rev. 07.01.2018) RFP Contract #PI\JC2119168P1 Page 27 of 109 BCF #202_ CS (Rev 07.01.2018) RFP Contract #PNC2119168P1 EXHIBIT A Scope of Services Page 28 of 109 SCOPE OF SERVICES CONTINUING ENGINEERING SERVICES FOR TRAFFIC, ROADWAY, AND CIVIL PROJECTS 1 GENERAL DESCRIPTION The Broward County Highway Construction and Engineering Division is requesting professional engineering and related services for traffic, roadway, and general civil engineering projects. The scope of services shall include all engineering specialties necessary and related to the design, engineering, study, analysis and evaluation, implementation, construction, and construction management of the projects and work efforts identified. All the work shall comply with the County, State and Federal roadway, civil and ancillary facilities construction standards as may be applicable. The following types of projects, but not limited to, are envisioned: 1. Traffic signalization intersection improvements for new mast arm supported traffic signals 2. Traffic signalization intersection improvements for traffic signal conversions from span-wire to mast arms 3. Advanced traffic management systems improvements, including adaptive signal control 4. Traffic signal engineering and communications system technology improvements including installation of fiber optic and cellular equipment and infrastructure 5. Intelligent transportation systems improvements 6. Intelligent transportation system software development 7. Vehicle detection camera systems improvements 8. Video detection predictive maintenance implementation 9. Transportation-related future technology adaptation systems 10. Overhead school zone flasher conversions to mast arms, including solar power conversions and relocation of school zone infrastructure to match modified school zone limits 11. Conversion of non-flashing school signs to signs with flashing beacons, including solar power installation and relocation of school zone infrastructure to match modified school zone limits 12. Pedestrian/bicycle/transit connector linkages 13. Traffic signal pedestrian displays BCF #202_CS (Rev. 07.01.2018) RFP Contract #PNC2119168P1 Page 29 of 109 14. Roadway alternative engineering and analysis 15. Roadway improvements, including widening, pavement, pedestrian facilities, bicycle facilities, drainage, water and sewer, lighting, etc. 16. Climate change resiliency drainage improvements including elevation adjustments, sea walls, storm pumping systems, green retention areas, tidal control 17. Greenway and sidewalk improvements 18. Miscellaneous civil engineering, design and related services, including the necessary incidentals, associated activities, and services required by a Work Authorization 19. Broward County In-House Consultant Support Services 2 PURPOSE The purpose of this Scope of Services document is to provide a broad description of the scope of the engineering services and the responsibilities of the CONSULTANT and the COUNTY in connection with the design and preparation of a complete set of construction contract plans, specifications, cost estimates, special provisions, etc., and studies, analyses, evaluations, and the requirements for any construction management services or implementation services to be provided. The construction management services would include construction engineering, inspection, testing, and all necessary contract administration work. An example for implementation services could include traffic signal network communications implementation including field deployment of equipment including firmware upgrades, establishing communications and troubleshooting, and providing data conversion services. The general objective is for the CONSULTANT to provide the engineering, design, studies, implementation, construction management and related services for each Work Authorization negotiated in accordance with the contract requirements. The final scope of services shall be established on a work authorization basis in accordance with Broward County requirements. The tasks described in the work authorizations scope of services shall include pertinent design or reference manuals that are necessary to define the requirements of the work. These items will be mutually agreed upon by both the COUNTY and the CONSULTANT. All plans and design documents are to be prepared with Standard English values in accordance with all applicable COUNTY, Florida Department of Transportation {FOOT), and Federal Highway Administration {FHWA) manuals and guidelines, as well as, other standards and manuals that may be documented. The CONSULTANT shall be aware that as a project work authorization is developed, certain modifications and/or improvements to the original recommendation may be required. The CONSULTANT is to incorporate these refinements into the design and will consider this effort to be an anticipated and integral part of the work. This will not be a basis for any BCF #202_CS (Rev 07.01 2018) RFP Conti-act #PNC2119168P1 Page 30 of 109 supplemental fee request{s}. The COUNTY shall have the final determination and approval for any amendments to any work authorization or to the contract agreement. The CONSULTANT shall demonstrate good project management practices while working on this contract. These practices include communication with the COUNTY, and others as necessary, management of time and resources, and proper documentation. The CONSULTANT shall set up and maintain throughout the design of any work authorization a contract file. It shall be the CONSULTANT's responsibility to utilize the very best engineering judgment, practices, and principles possible during the prosecution of the work negotiated under this contract. The COUNTY will provide contract administration, management services, and technical reviews of all work associated with the development and preparation of the contract plans and during project implementation or the construction management services provided by the CONSULTANT. The COUNTY will provide job specific information and/or functions as outlined in the contract. COUNTY shall request work authorizations on an as-needed basis. There is no guarantee that any or all the services described in this document will be assigned during the term of this agreement. COUNTY, at its option, may elect to have any of the services set forth herein performed by other consultants or County staff. 3 FOOT PREQUALIFICATION AND OTHER REQUIREMENTS The CONSULTANT and its sub-consultants shall be collectively prequalified {FOOT Prequalification Letter Required} for the following FOOT Work Groups pursuant to law {Rule 14-75, Florida Administrative Code {F.A.C.}: Type of Work 3.1: Type of Work 3.2: Type of Work 4.1.1: Type of Work 6.1: Type of Work 6.2: Type of Work 6.3.1: Type of Work 6.3.2: Type of Work 6.3.3: Type of Work 6.3.4: Type of Work 7.1: Type of Work 7.2: Type of Work 7.3: Type of Work 8.1: Type of Work 8.2: Type of Work 8.4: Type of Work 9.1: Type of Work 9.2: Minor Highway Design Major Highway Design Miscellaneous Structures Traffic Engineering Studies Traffic Signal Timing Intelligent Transportation Systems Analysis and Design Intelligent Transportation Systems Implementation Intelligent Transportation Traffic Engineering Systems Communications Intelligent Transportation System Software Development Signing, Pavement Marking, and Channelization Lighting Signalization Control Surveying Design, Right of Way, and Construction Surveying Right of Way Mapping Soil Exploration Geotechnical Classification Lab Testing BCF #202_CS (Rev. 07.01 2018) RFP Contract #PNC2119168P1 Page 31 of 109 Type of Work 9.3: Type of Work 9.4.1: Type of Work 9.5: Highway Materials Testing Standard Foundation Studies Geotechnical Specialty Lab Testing Type of Work 10.1: Type of Work 10.3: Roadway Construction, Engineering and Inspection {CEI} Construction Materials Inspection Type of Work 10.4: Type of Work 15.0: Minor Bridge and Miscellaneous Structures CEI Landscape Architect The CONSULTANT and/or its sub-consultants shall have at least one individual for each of the following International Municipal Signal Association {IMSA) certifications. Only those individuals certified in these specialty areas may perform the associated inspection services and all certified personnel shall be available to perform the inspection services required for the installation, maintenance, and operations of the traffic control equipment and devices. All certifications {documentation) shall be submitted at the time of the Request for Proposal {RFP) solicitation and shall be maintained and kept current during the contract duration. 1. IMSA Traffic Signal Construction Technician Level II 2. IMSA Traffic Signal Technician 3. IMSA Traffic Signal Inspector {Florida Edition) The CONSULTANT and/or its sub-consultants shall have at least one individual that has completed the following training: 1. Advanced Maintenance-of-Traffic {MOT} Training through an approved FDOT Provider The CONSULTANT and/or its sub-consultants performing Construction Engineering and Inspection {CEI} services shall have at least one individual in each category listed below that are certified by FDOT for the following Construction Training and Qualification Program {CTQP} areas of expertise: 1. Asphalt Paving Level 2 2. Concrete Field Inspector Specification Level 1 3. Earthwork Construction Inspection Level 1 4. Drilled Shaft Inspection 5. Quality Control {QC} Manager 6. Final Estimates Level 2 BCF #202_CS (Rev 07 01 2018) RF P Contract #PNC2119168P 1 Page 32 of 109 The COUNTY shall approve all CEI personnel prior to performance of any CEI services, and the administration of all CEI staff shall be under the responsible charge of a Florida Licensed Professional Engineer. All certifications (documentation) shall be submitted at the time of the RFP solicitation and shall be maintained and kept current during the contract duration. 4 ENGINEERING DESIGN AND RELATED SERVICES The overall work will consist of multiple work authorizations for the completion of various engineering designs and preparation of contract documents, field deployments, construction inspections, and related services with regards to the assigned projects. The specific projects will be identified in each year of the contract based on a priority established at the time by the COUNTY. Generally, the work authorizations will include those types of services required for the types of projects listed above. The CONSULTANT shall investigate the status of each assigned work authorization and become familiar with the existing site conditions, contract requirements, deliverables, and commitments regarding schedule in order to enter into negotiations with the COUNTY. The CONSULTANT shall use the approved scope of services, design concepts, and types of services required as a basis for the work authorization unless otherwise directed by the COUNTY. The CONSULTANT shall be responsible for preparing a detailed scope of services for each work authorization issued throughout the duration of the contract prior to negotiations for the work authorization being issued. 5 PROJECT SCHEDULE Within ten (10) days after the Notice-To-Proceed (NTP) for each approved and negotiated work authorization, and prior to the CONSULTANT beginning work, the CONSULTANT shall provide a detailed project activity/event schedule for COUNTY and CONSULTANT scheduled activities required to meet the current COUNTY Delivery Date. The schedule shall be accompanied by an anticipated payout and fiscal progress curve. For the purpose of scheduling, the CONSULTANT shall allow for COUNTY review time for each phase and other submittals as appropriate. All fees and price proposals are to be based on the negotiated schedule for final plans production, studies, network implementation, and/or construction schedules for CEI services. Periodically, throughout the life of any assigned project, the schedule and payout curves shall be reviewed and, with the approval of the COUNTY, adjusted as necessary to incorporate changes in the work concept and progress to date. The approved schedule and schedule status report, along with progress, shall be submitted with the monthly progress BCF #202_ CS (Rev. 07 01 .2018) RFP Contract #PNC2119168P1 Page 33 of 109 report. The schedule shall be submitted in Microsoft Projects, Suretrak, Primavera, or system compatible format. 6 ENGINEERING, DESIGN, PLAN PREPARATION, AND RELATED SERVICES The CONSULTANT shall be responsible for preparing a detailed scope of services for each work authorization issued throughout the duration of the contract prior to negotiation and revise as needed without compensation. The scope of services shall include the types of services required for the task order being negotiated, and may include the following: 1. Records research and data collection 2. Field site visit and review of project requirements and constraints 3. Field surveying and base mapping 4. Right-of-way engineering 5. Preliminary engineering and alternatives analysis 6. Geotechnical investigations, sampling, testing, and report documentation 7. Subsurface utility engineering {SUE} 8. Project coordination and documentation 9. Utility coordination and documentation 10. Utility conflicts evaluation and design 11. Agency coordination and permitting 12. Environmental engineering 13. Roadway design and plans preparation 14. Site engineering and design 15. Pavement design 16. Utilities design 17. Drainage design 18. Stormwater pollution prevention plans 19. Miscellaneous structures design 20. Foundations design 21. Signing and pavement markings 22. Traffic signalization design 23. Maintenance of traffic design 24. School zone design BCF #202_CS (Rev. 07.01 2018) RFP Contract #PNC2119168P1 Page 34 of 1 09 25. Lighting design 26. Miscellaneous engineering and studies 27. Traffic data collection 28. Traffic control design 29. Traffic engineering and operations reports 30. Traffic communications systems design and/or implementation 31. Intelligent transportation systems design 32. Engineering reports 33. Technical specifications 34. Public involvement activities 35. Permitting 36. Construction cost estimating 37. Bid and contract award 38. As-built records engineering 39. Plans review 40. Construction engineering inspections 41. Construction administration and management 42. Critical Path Method {CPM) scheduling 43. Value engineering 44. In-House Professional Engineering and support 45. Landscape architecture The CONSULTANT shall furnish plans and documents as required by the COUNTY to adequately control, coordinate, and approve the plans and other contract deliverables. The CONSULTANT shall distribute phase submittals as directed by the COUNTY. In addition, the CONSULTANT shall furnish plans and documents to other Government Agencies as required to obtain approvals and/or permits. The COUNTY and other Government Agencies will determine the specific number of copies required prior to each submittal. The CONSULTANT shall meet COUNTY, FDOT and other governmental agency's requirements during the various stages of the process to design and prepare the complete set of construction contract plans and special provisions. The CONSULTANT shall produce designs, alternatives, evaluations, analyses, contract plans, specifications, cost estimates, and obtain the necessary permits required for each work authorization project assigned. These documents shall contain all construction details, contract provisions, permits, reports, BCF #202_CS (Rev 07.01 2018) RFP Contract #PNC2119168P1 Page 35 of 109 agreements, and certifications required to advertise, award, and administer a construction contract. The CONSULTANT shall prepare and submit required documents in accordance with the latest FOOT Green Book and Design Manual at the time of the work authorization. The CONSULTANT shall be aware that the number of submittals and phase reviews is determined on a project by project basis and no design phase is complete until all review comments have been resolved and documented. It is the responsibility of the CONSULTANT to address and resolve all review comments during design phases. The CONSULTANT shall prepare and submit items listed for each phase submittal at the time of negotiations of the work authorization. Note that requirements are not limited, and it is the responsibility of the CONSULTANT to investigate and meet all requirements. 7 TRAFFIC NETWORK COMMUNICATIONS IMPLEMENTATION OR MODIFICATION The CONSULTANT shall be responsible for preparing a detailed scope of services for each work authorization issued throughout the duration of the contract prior to negotiations for the work order being issued. The scope of services may include field coordination and implementation of migration services for the traffic signal system for various intersections located within the County. The services include making modifications to the operation of the signals by converting the signal controllers from one type of communication protocol to another type. This process requires specialized expertise in three primary areas as follows: 1. Field traffic signal controller firmware implementation, operation, updates and verification 2. Communications equipment setup, testing, and field deployment and troubleshooting for fiber optics and cellular devices 3. Signal timing methods and procedures The field signal firmware procedures are generally characterized as traffic signal technician tasks, the communications setup work are network engineering tasks, and traffic signal timing are engineering functions. The CONSULTANT will be required to provide coordination efforts with Broward County Traffic Engineering, and Highway Construction and Engineering Divisions staff since the work requires specific knowledge only available from the COUNTY. The COUNTY utilizes Naztec 2070 traffic signal controllers, fiber optic switches, cellular modems and air cards, and cellular antennas within its communications network. This equipment, and its use and testing, requires specialized skills and expertise in order to ensure consistency within the signal communications network. Signal verification, troubleshooting, and communications issue resolution are required and are an integral part of the implementation process. BCF #202_CS (Rev. 07 01.2018) RFP Contract#PNC2119168P1 Page 36 of 109 8 CONSTRUCTION MANAGEMENT SERVICES The CONSULTANT shall be responsible for preparing a detailed scope of services for each work authorization issued throughout the duration of the contract prior to negotiations of the work order being issued. The scope of services for the construction engineering and inspection (CEI) shall include the types of services required for the task order being negotiated, and may include the following: 1. Management of CEI contract assignments 2. Issue identification and resolution 3. Project communications, coordination and documentation 4. On-site inspection 5. Contract administration 6. Permit monitoring 7. Public concerns coordination 8. Construction cost and schedule control 9. Materials sampling and testing 10. Engineering services 11. Geotechnical engineering services 12. Review of construction documents 13. Certification of interim and final estimates 14. Review of contractor invoices 15. Post construction claims review 16. Shop drawings review and processing 17. Request for Information (RFI) review and processing 18. Change order review and processing 19. Value engineering 9 SERVICES TO BE PERFORMED BY THE COUNTY 1. When appropriate the COUNTY will provide project data currently on file 2. Provide phase reviews of plans and engineering documents 3. Furnish COUNTY agreements with Utility Agency Owner (UAO), as available 4. Furnish COUNTY agreements with municipalities BCF #202_CS (Rev 07.01.2018) RFP Conti-act #PNC2119168P1 Page 37 of 109 5. Provide all information that may come to the COUNTY pertaining to future improvements 6. Attend scheduled meetings with the consultant to discuss project requirements, issues, schedules, documents, etc. 10 PROJECT COMMON TASKS Project common tasks, as listed below, are work efforts that are applicable to many project activities. These tasks are to be included in the project scope in each applicable activity when the described work is to be performed by the CONSULTANT. Cost Estimates: The CONSULTANT shall be responsible for producing a construction cost estimate and reviewing and updating the cost estimate when scope changes occur and/or at milestones of the project. A Summary of Pay Items sheet shall be prepared with all required plans submittals. Technical Special Provisions: The CONSULTANT shall provide Technical Special Provisions for all items of work not covered by the FDOT Standard Specifications for Road and Bridge Construction and the workbook of implemented modifications. All modifications to sections must be justified to the COUNTY to be included in the project's specifications package, typically as special provisions and not as Technical Special Provisions. The Technical Special Provisions shall be technical in nature and shall provide a description of work, materials, equipment and specific requirements, installation, warranty, method of measurement and basis of payment. Proposed Technical Special Provisions will be submitted to the COUNTY for review at the time of plans review submission to the COUNTY. The Technical Special Provisions will be reviewed for suitability in accordance with the COUNTY standards and FDOT Handbook for Preparation of Specification Package. Field Reviews: Includes all trips required to obtain necessary data for all elements of the project. Technical Meetings: Includes meetings with COUNTY and/or Agency staff, between disciplines and subconsultants, such as management meetings, design meetings, local governments, railroad companies, utility owners, progress review meetings (phase review}, and miscellaneous meetings. The CONSULTANT shall prepare, and submit to the COUNTY's Project Manager for review, the meeting minutes for all meetings attended by them. The meeting minutes are due within five (5} days of attending the meeting. The CONSULTANT shall also meet with the COUNTY to review the Project scope as well as to discuss any possible right-of-way and/or environmental concerns and overall Project feasibility. In addition, the CONSULTANT shall coordinate with applicable environmental agencies. BCF #202_ CS (Rev. 07 01 .2018) RFP Contract #PNC21191G8P1 Page 38 of 109 Quality Assurance/Quality Control: It is the intention of the COUNTY that design CONSULTANTS are held responsible for their work and their subconsultants, including plans review. Detailed checking of CONSULTANT plans or assisting in designing portions of the project for the CONSULTANT is not the intent of having external design consultants. The purpose of CONSULTANT plan reviews is to ensure that CONSULTANT plans follow the plan preparation procedures outlined in the FOOT Design Manual, that state and federal design criteria are followed with the COUNTY concept, and that the CONSULTANT submittals are complete. The CONSULTANT shall be responsible for the professional quality, technical accuracy and coordination of all surveys, designs, drawings, specifications, and other services furnished by the CONSULTANT and sub-consultants under this contract. The CONSULTANT shall provide a Quality Control Plan that describes the procedures to be utilized to verify, independently check, and review all maps, design drawings, specifications, and other documentation prepared as a part of the contract. The CONSULTANT shall describe how the checking and review processes are to be documented to verify that the required procedures were followed. The Quality Control Plan shall be one specifically designed for this project. The Quality Control Plan may be one utilized by the CONSULTANT as part of their normal operation or it may be one specifically designed for this project. The CONSULTANT shall submit a Quality Control Plan for approval within 20 (twenty) calendar days of the written Notice to Proceed. A marked up set of prints from a Quality Control Review indicating the reviewers for each component (structures, roadway, drainage, signals, geotechnical, signing and marking, lighting, surveys, etc.) and a written resolution of comments on a point-by-point basis will be required, if requested by the COUNTY, with each phase submittal. The responsible Professional Engineer, Landscape Architect, or Professional Surveyor & Mapper that performed the Quality Control review will sign a statement certifying that the review was conducted and found to meet required specifications. The CONSULTANT shall, without additional compensation, correct all errors or deficiencies in the designs, maps, drawings, specifications, and/or other services. Independent Peer Review: When directed by the COUNTY, a subconsultant may perform Independent Peer Reviews. Supervision: Includes all efforts required to supervise all technical design activities, field implementations, and construction management services provided. Coordination: Includes all efforts to coordinate with all disciplines of a project to produce a final set of construction documents, to finalize signal or network implementation, or to provide construction engineering and inspection. BCF #202_ CS (Rev 07.01 2018) RFP Contract #PNC2119168P1 Page 39 of 109 11 PROJECT GENERAL TASKS Project General Tasks represent work efforts that are applicable to a project as a whole and not to any one or more specific project activities. The work described in these tasks shall be performed by the CONSULTANT when included in the project scope. Public Involvement: Public involvement includes communicating to all interested persons, groups, and government organizations information regarding the development of the project. The CONSULTANT shall provide to the COUNTY drafts of all Public Involvement documents (i.e., newsletters, property owner letters, advertisements, etc.) associated with the following tasks for review and approval at least five (5) business days prior to printing and/or distribution. 1. Community Awareness Plan 2. Notifications 3. Preparing Mailing Lists 4. Median Modification Letters 5. Driveway Modification Letters 6. Newsletters 7. Renderings and Fly-Throughs 8. PowerPoint Presentations 9. Public Meeting Preparations 10. Public Meeting Attendance and Follow-up 11. Broward Metropolitan Planning Organization (MPO) Meetings Contract Maintenance: Includes project management effort for complete setup and maintenance of files, developing monthly progress reports, schedule updates, work effort to develop and execute subconsultant agreements, etc. Plans Update: Includes effort needed to update plans and will vary from project to project, depending on size and complexity of the project, as well as the duration of time spent "on the shelf". Post Design Services: Includes, but is not limited to, meetings, construction assistance, plans revisions, shop drawing review, survey services and load ratings. Specific services will be negotiated as necessary as a contract amendment. Post Design Services are not intended for instances of CONSULTANT errors and/or omissions. BCF #202_CS (Rev. 07.01.2018) RFP Contract #PNC2119168P1 Page 40 of 109 Electronic Delivery: The CONSULTANT shall deliver final contract plans in electronic format. The final contract plans shall be electronically signed, and sealed files delivered to the COUNTY on acceptable electronic media, as determined by the COUNTY. 12 PROJECT REQUIREMENTS Liaison Office: The COUNTY and the CONSULTANT will designate a Liaison Office and a Project Manager who shall be the representative of their respective organizations for the Project{s). While it is expected the CONSULTANT shall seek and receive advice from various state, regional, and local agencies, the final direction on all matters of any work authorization issued under this agreement remains with the COUNTY Contract Administrator and Project Manager. Key Personnel: The CONSULTANT's work shall be performed and directed by the key personnel identified in the proposal presentations by the CONSULTANT. Any changes in the indicated personnel shall be subject to review and approval by COUNTY. Progress Reporting: The CONSULTANT shall meet with the COUNTY as required and shall provide a written progress and schedule status reports that describe the work performed on each task. Progress and schedule status reports shall be delivered to the COUNTY concurrently with the monthly invoice. The Project Manager will make judgment on whether work of sufficient quality and quantity has been accomplished by comparing the reported percent complete against actual work accomplished. Correspondence: Copies of all written correspondence between the CONSULTANT and any party pertaining specifically to this contract shall be provided to the COUNTY for their records within one (1) week of the receipt or mailing of said correspondence. Professional Endorsement: The CONSULTANT shall have a Registered Professional Engineer in the State of Florida sign and seal all reports, documents, and plans as required by COUNTY standards. Computer Automation: Projects will be developed utilizing Computer-Aided Drafting and Design {CADD} systems, as appropriate. It is the responsibility of the CONSULTANT to meet the requirements in the FOOT CADD Manual and any COUNTY requirements. The CONSULTANT will submit final documents and files as described therein and as required by the COUNTY's Project Manager. Coordination with Other Consultants: The CONSULTANT is to coordinate its work with any and all consultants who may be working on adjacent projects to effectively complete well- coordinated plans and specifications for the project{s) under this agreement. BCF #202_CS (Rev. 07.01.2018) RFP Contract #PNC2119168P 1 Page 41 of 109 EXHIBIT B Payment Schedule The rates specified below shall be in effect for the entire term of the Agreement, including any renewal or extension term(s}, unless otherwise expressly stated. Any goods or services required under this Agreement for which no specific fee or cost is expressly stated in this Payment Schedule shall be deemed to be included, at no extra cost, within the costs and fees expressly provided for in this Exhibit B. BCF #202_CS (Rev. 07 01 .2018) RFP Contract #PNC2119168P1 Page 42 of 109 EXHIBIT B MAXIMUM BILLING RATES - HOME OFFICE Contract No: PNC2119168P1 Contract Title: Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering, Inc. Subconsultant Name: MAXIMUM MULTIPLIER BILLING MAXIMUM 2.96 RATE HOURLY RATE ($/HR) TITLE ($/HR) X = Chief Engineer 2 $92.67 2.96 $250.00* Project Manager 3 $91.35 2.96 $250.00* Project Manager 2 $89.41 2.96 $250.00* Senior Engineer 2 $79.80 2.96 $236.21 Senior Electrical Engineer $74.55 2.96 $220.67 Senior Engineer 1 $71.60 2.96 $211.94 Project Manager 1 $65.79 2.96 $194.74 Engineer 2 $62.73 2.96 $185.68 Senior Computer Programmer $62.00 2.96 $183.52 Senior Environmental Specialist $56.71 2.96 $167.86 Senior Designer $49.45 2.96 $146.37 Senior Utility Coordinator $49.22 2.96 $145.69 Engineer 1 $48.21 2.96 $142.70 GIS Specialist $43.30 2.96 $128.17 Designer $37.74 2.96 $111.71 Engineering Intern $34.96 2.96 $103.48 (ADD/Computer Technician $31.97 2.96 $94.63 Environmental Specialist $31.64 2.96 $93.65 Engineering Technician $27.89 2.96 $82.55 Multiplier of 2.96 is calculated as follows: OVERHEAD= HOURLY RATE X OVERHEAD (103.57) % FRINGE= HOURLY RATE X FRINGE (65.43) % OPERATING MARGIN= (HOURLY RATE+ OVERHEAD+ FRINGE) X OPERATING MARGIN (10.00) % MULTIPLIER= (HOURLY RATE+ OVERHEAD+ FRINGE+ OPERATING MARGIN}/ HOURLY RATE Note: *Maximum Billing Rates will not exceed $250.00/HR. BCF #202_ CS (Rev. 07 01 .2018) RFP Contract#PNC2119168P1 Page 43 of 109 EXHIBIT B-1 MAXIMUM BILLING RATES - FIELD OFFICE Contract No: PNC2119168P1 Contract Title: Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering, Inc. Subconsultant Name: MAXIMUM MAXIMUM MULTIPLIER BILLING HOURLY 2.31 RATE RATE TITLE ($/HR) X = ($/HR) CEI Senior Project Engineer $73.58 2.31 $169.97 CEI Project Administrator/CE! Project Engineer $50.52 2.31 $116.70 CEI Senior ITS Inspector $36.10 2.31 $83.39 CEI Senior Inspector/Senior Engineer Intern $35.10 2.31 $81.08 CEI ITS Inspector $30.04 2.31 $69.39 CEI Inspector/Engineer Intern $26.25 2.31 $60.64 Multiplier of 2.31 is calculated as follows: OVERHEAD= HOURLY RATE X OVERHEAD (43.20) % FRINGE= HOURLY RATE X FRINGE (66.88) % OPERATING MARGIN= (HOURLY RATE+ OVERHEAD+ FRINGE) X OPERATING MARGIN (10.00) % MULTIPLIER= (HOURLY RATE+ OVERHEAD+ FRINGE+ OPERATING MARGIN)/ HOURLY RATE DIRECT EXPENSE RATE= 16.84% BCF #202_CS (Rev. 07.01 2018) RFP Contract #Pt\JC2119168P1 Page 44 of 109 EXHIBIT B MAXIMUM BILLING RATES - HOME OFFICE Contract No: PNC2119168P1 Contract Title: Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering Subconsultant Name: ADEPT Public Relations, LLC MULTIPLIER MAXIMUM MAXIMUM 2.31 BILLING RATE HOURLY RATE TITLE ($/HR) X = ($/HR) Project Manager 3 $91.35 2.31 $211.02 Community Outreach Specialist - $45.67 2.31 $105.50 Senior Community Outreach Specialist - $45.67 2.31 $105.50 Senior -Video Production Multiplier of 2.31 is calculated as follows: OVERHEAD= HOURLY RATE X OVERHEAD (110.00) % FRINGE= HOURLY RATE X FRINGE (0.00) % OPERATING MARGIN= (HOURLY RATE+ OVERHEAD+ FRINGE) X OPERATING MARGIN (10.00) % MULTIPLIER= (HOURLY RATE+ OVERHEAD+ FRINGE+ OPERATING MARGIN)/ HOURLY RATE Notes: Subconsultant has elected to use "Safe Harbor" combined fringe benefit and overhead rate of 110% in accordance with

2.5. BCF #202_CS (Rev 07.01.2018) RFP Contract #PNC2119168P1 Page 45 of 109 EXHIBIT B MAXIMUM BILLING RATES - HOME OFFICE Contract No: PNC2119168Pl Contract Title: Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering, Inc. Subconsultant Name: BMA Consulting Engineering, Inc. MAXIMUM MAXIMUM BILLING HOURLY MULTIPLIER RATE RATE 2.66 TITLE ($/HR) X = ($/HR) Senior Engineer 2 $79.80 2.66 $212.27 Senior Engineer 1 $71.60 2.66 $190.46 Engineer 2 $62.73 2.66 $166.86 Senior Environmental Specialist $56.71 2.66 $150.85 Senior Designer $49.45 2.66 $131.54 Designer $37.74 2.66 $100.39 Multiplier of 2.66 is calculated as follows: OVERHEAD= HOURLY RATE X OVERHEAD (102.26) % FRINGE= HOURLY RATE X FRINGE (39.27) % OPERATING MARGIN= (HOURLY RATE+ OVERHEAD+ FRINGE) X OPERATING MARGIN (10.00) % MULTIPLIER= (HOURLY RATE+ OVERHEAD+ FRINGE+ OPERATING MARGIN)/ HOURLY RATE BCF #202_ CS (Rev 07.01.2018) RFP Contract #t'NC2119168P1 Page 46 of 1 09 EXHIBIT B MAXIMUM BILLING RATES - HOME OFFICE Contract No: PNC2119168P1 Contract Title: Consultant Subconsultant Name: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering, Inc. Compass Point Surveyors, PL MAXIMUM BILLING MAXIMUM MULTIPLIER RATE HOURLY RATE 2.31 TITLE ($/HR) X = ($/HR) SUR Project Manager 1 $65.79 2.31 $151.97 SUR Chief Surveyor $62.92 2.31 $145.35 SUR Project Surveyor $55.29 2.31 $127.72 SUR Field Crew Supervisor II $50.48 2.31 $116.61 Multiplier of 2.31 is calculated as follows: OVERHEAD= HOURLY RATE X OVERHEAD {110.00) % FRINGE= HOURLY RATE X FRINGE (0.00) % OPERATING MARGIN= (HOURLY RATE+ OVERHEAD+ FRINGE) X OPERATING MARGIN (10.00) % MULTIPLIER= (HOURLY RATE+ OVERHEAD+ FRINGE+ OPERATING MARGIN)/ HOURLY RATE Notes: Subconsultant has elected to use "Safe Harbor" combined fringe benefit and overhead rate of 110% in accordance with

2.5. BCF #202_ CS (Rev. 07 01 .2018) RFP Contract #PNC2119168P1 Page 47 of 109 EXHIBIT B-2 REIMBURSABLES Project No: PNC2119168Pl Project Title: Consultant/ Subconsultant Name: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering, Inc. Compass Point Surveyors, PL UNIT PRICE REIMBURSABLES ITEM UNIT UNIT PRICE Survey Crew - 2 Person Per Crew ($/HR) $130.00 Survey Crew - 3 Person Per Crew ($/HR) $160.00 Survey Crew - 4 Person Per Crew ($/HR) $200.00 Note: The unit prices shown above include all materials, labor, equipment, overhead and profit for the field data collection, evaluation, analysis, and documentation for use in the project deliverables. BCF #202_CS (Rev 07.01.2018) RFP Contract #PNC2119168P1 Page 48 of 109 EXHIBIT B MAXIMUM BILLING RATES - HOME OFFICE Contract No: PNC2119168Pl Contract Title: Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering, Inc. Subconsultant Name: Duland Design LLC MAXIMUM BILLING MULTIPLIER RATE MAXIMUM 2.31 HOURLY RATE TITLE ($/HR) X = ($/HR) Senior Landscape Architect $57.82 2.31 $133.56 Project Landscape Architect $50.00 2.31 $115.50 Landscape Architect Intern $32.09 2.31 $74.13 Multiplier of 2.31 is calculated as follows: OVERHEAD= HOURLY RATE X OVERHEAD (110.00) % FRINGE= HOURLY RATE X FRINGE (0.00) % OPERATING MARGIN= (HOURLY RATE+ OVERHEAD+ FRINGE) X OPERATING MARGIN (10.00) % MULTIPLIER= (HOURLY RATE+ OVERHEAD+ FRINGE+ OPERATING MARGIN)/ HOURLY RATE Notes: Subconsultant has elected to use "Safe Harbor" combined fringe benefit and overhead rate of 110% in accordance with

2.5. BCF #202_CS (Rev. 07.01.2018) RFP Contract #PNC2119168P1 Page 49 of 109 EXHIBIT B MAXIMUM BILLING RATES- HOME OFFICE Project No: PNC2119168Pl Project Title: Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering, Inc. Subconsultant Name: EBS Engineering, Inc. MAXIMUM MULTIPLIER MAXIMUM HOURLY 3.00 BILLING RA TE RATE TITLE ($/HR} X = ($/HR} Project Manager 3 $91.35 3.00 $250.00* Project Manager 2 $89.41 3.00 $250.00* Senior Engineer 2 $79.80 3.00 $239.40 Senior Engineer 1 $71.60 3.00 $214.80 Project Manager 1 $65.79 3.00 $197.37 Engineer 2 $62.73 3.00 $188.19 Senior Environmental Specialist $56.71 3.00 $170.13 Engineer 1 $48.21 3.00 $144.63 Engineering Intern $34.96 3.00 $104.88 CADD/Computer Technician $31.97 3.00 $95.91 Multiplier of 3.00 is calculated as follows: OVERHEAD= HOURLY RATE X OVERHEAD (126.47) % FRINGE = HOURLY RATE X FRINGE (46.26) % OPERATING MARGIN= (HOURLY RATE+ OVERHEAD+ FRINGE) X OPERATING MARGIN (10.00) % MULTIPLIER= (HOURLY RATE+ OVERHEAD+ FRINGE+ OPERATING MARGIN/ HOURLY RATE Note: *Maximum Billing Rates will not exceed $250.00/HR. BCF #202 __ cs (Rev. 07.01.2018) RFP Contract #PNC2119168F)1 Page 50 of 109 EXHIBIT B-1 MAXIMUM BILLING RATES - FIELD OFFICE Project No: PNC2119168P1 Project Title: Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering, Inc. Subconsultant Name: EBS Engineering, Inc. MAXIMUM MULTIPLIER MAXIMUM TITLE HOURLY 2.31 BILLING RATE RATE ($/HR) ($/HR) X = CEI Senior Inspector/ Senior Engineer Intern $35.10 2.31 $81.08 CEI ITS Inspector $30.04 2.31 $69.39 Multiplier of 2.31 is calculated as follows: OVERHEAD= HOURLY RATE X OVERHEAD (110.00) % FRINGE = HOURLY RATE X FRINGE (0.00) % OPERATING MARGIN= (HOURLY RATE+ OVERHEAD+ FRINGE) X OPERATING MARGIN (10.00) % MULTIPLIER= (HOURLY RATE+ OVERHEAD+ FRINGE+ OPERATING MARGIN/ HOURLY RATE Notes: Subconsultant has elected to use "Safe Harbor" combined fringe benefit and overhead rate of 110% For Construction Engineering and Inspection Services. DIRECT EXPENSE RATE= 0.00% BCF #202_CS (Rev. 07.01.2018) RFP Contract #PNC2119168P1 Page 51 of 109 Contract No: Contract Title: Consultant: Subconsultant Name: EXHIBIT B-1 MAXIMUM BILLING RATES - FIELD OFFICE PNC2119168P1 Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering, Inc. F&J Engineering Group, Inc. MAXIMUM MAXIMUM MULTIPLIER BILLING HOURLY RATE RATE 2.45 TITLE ($/HR) X = ($/HR) CEI Project Administrator/CE! Project Engineer $50.52 2.45 $123.77 CEI Contract Support Specialist $37.92 2.45 $92.90 CEI Senior Bridge Inspector $37.61 2.45 $92.14 CEI Senior ITS Inspector $36.10 2.45 $88.45 CEI Senior Roadway Inspector $36.10 2.45 $88.45 CEI ITS Inspector $30.04 2.45 $73.60 CEI Roadway Inspector $30.04 2.45 $73.60 CEI Bridge Inspector $28.27 2.45 $69.26 CEI Resident Compliance Specialist $25.00 2.45 $61.25 Multiplier of 2.45 is calculated as follows: OVERHEAD= HOURLY RATE X OVERHEAD (78.71) % FRINGE= HOURLY RATE X FRINGE (43.87) % OPERATING MARGIN= (HOURLY RATE+ OVERHEAD+ FRINGE) X OPERATING MARGIN (10.00) % MULTIPLIER= (HOURLY RATE+ OVERHEAD+ FRINGE+ OPERATING MARGIN)/ HOURLY RATE DIRECT EXPENSE RATE= 12.25% BCF #202_CS (Rev. 07.01 2018) RFP Contract#PNC2119168P1 Page 52 of 109 EXHIBIT BAND 8-1 MAXIMUM BILLING RATES - HOME AND FIELD OFFICE Contract No: PNC2119168P1 Contract Title: Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering, Inc. Subconsultant Name: Florida Engineering & Testing, Inc. MAXIMUM MAXIMUM MULTIPLIER BILLING HOURLY RATE RATE ($/HR) 2.31 ($/HR) TITLE X = Project Manager 1 $65.79 2.31 $151.97 Engineer 1 $48.21 2.31 $111.37 Field/Lab Crew Supervisor I $34.41 2.31 $79.49 Senior Engineering Technician $34.00 2.31 $78.54 Engineering Technician $27.89 2.31 $64.43 CEI Secretary/Clerical $27.00 2.31 $62.37 CEI Inspector/Engineer Intern $26.25 2.31 $60.64 Multiplier of 2.31 is calculated as follows: OVERHEAD= HOURLY RATE X OVERHEAD (110.00) % FRINGE= HOURLY RATE X FRINGE (0.00) % OPERATING MARGIN= (HOURLY RATE+ OVERHEAD+ FRINGE) X OPERATING MARGIN (10.00) % MULTIPLIER= (HOURLY RATE+ OVERHEAD+ FRINGE+ OPERATING MARGIN)/ HOURLY RATE Notes: Subconsultant has elected to use "Safe Harbor'' comb·ined fringe benefit and overhead rate of 110% in accordance with

2.5. DIRECT EXPENSE RATE= 0.00% BCF #202_CS (Rev. 07 01.2018) RFP Contract #PNC2119168P1 Page 53 of 109 EXHIBIT B MAXIMUM BILLING RATES - HOME OFFICE Contract No: PNC2119168Pl Contract Title: Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering, Inc. Subconsultant Name: HP Consultants, Inc. MAXIMUM MULTIPLIER BILLING MAXIMUM RATE HOURLY RATE 3.00 TITLE ($/HR) X = ($/HR} Project Manager 2 $89.41 3.00 $250.00* Chief Engineer 1 $80.46 3.00 $241.38 Senior Engineer 1 $71.60 3.00 $214.80 Engineer 1 $48.21 3.00 $144.63 Designer $37.74 3.00 $113.22 Utility Coordinator $35.70 3.00 $107.10 CADD/Computer Technician $31.97 3.00 $95.91 Secretary/Clerical $27.00 3.00 $81.00 Multiplier of 3.00 is calculated as follows: OVERHEAD= HOURLY RATE X OVERHEAD (140.00) % FRINGE= HOURLY RATE X FRINGE (32.50) % OPERATING MARGIN= (HOURLY RATE+ OVERHEAD+ FRINGE) X OPERATING MARGIN (10.00) % MULTIPLIER= (HOURLY RATE+ OVERHEAD+ FRINGE+ OPERATING MARGIN)/ HOURLY RATE Note: *Maximum Billing Rates will not exceed $250.00/HR. BCF #202 __ CS (Rev 07 01 .2018) RFP Contract #PNC2119168P1 Page 54 of 109 EXHIBIT B-1 MAXIMUM BILLING RATES - FIELD OFFICE Contract No: PNC2119168Pl Contract Title: Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering, Inc. Subconsultant Name: HP Consultants, Inc. MAXIMUM MULTIPLIER BILLING MAXIMUM RATE HOURLY RATE 2.31 TITLE ($/HR) X = ($/HR) CEI Senior Inspector/Senior Engineer Intern $35.10 2.31 $81.08 CEI Inspector/Engineer Intern $26.25 2.31 $60.64 Multiplier of 2.31 is calculated as follows: OVERHEAD= HOURLY RATE X OVERHEAD (110.00) % FRINGE= HOURLY RATE X FRINGE (0.00) % OPERATING MARGIN= (HOURLY RATE+ OVERHEAD+ FRINGE) X OPERATING MARGIN (10.00) % MULTIPLIER= (HOURLY RATE+ OVERHEAD+ FRINGE+ OPERATING MARGIN)/ HOURLY RATE Notes: Subconsultant has elected to use "Safe Harbor" combined fringe benefit and overhead rate of 110% in accordance with

2.5. DIRECT EXPENSE RATE= 0.00% BCF #202 __ cs (Rev. 07.01 2018) RFP Contract #PNC2119168P1 Page 55 of 109 EXHIBIT B MAXIMUM BILLING RATES - HOME OFFICE Contract No: PNC2119168P1 Contract Title: Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering, Inc. Subconsultant Name: lteris, Inc. MAXIMUM MULTIPLIER MAXIMUM HOURLY RATE BILLING RATE ($/HR) TITLE X = ($/HR) 3.00 Chief Engineer 2 $92.67 3.00 $250.00* Project Manager 3 $91.35 3.00 $250.00* Chief Engineer 1 $80.46 3.00 $241.38 Engineer 2 $62.73 3.00 $188.19 Senior Designer $49.45 3.00 $148.35 Engineer 1 $48.21 3.00 $144.63 Transportation Data Analyst $44.52 3.00 $133.56 Engineering Intern $34.96 3.00 $104.88 Senior Engineering Technician $34.00 3.00 $102.00 Engineering Technician $27.89 3.00 $83.67 Multiplier of 3.00 is calculated as follows: OVERHEAD= HOURLY RATE X OVERHEAD (100.94) % FRINGE = HOURLY RATE X FRINGE (71.78) % OPERATING MARGIN= (HOURLY RATE+ OVERHEAD+ FRINGE) X OPERATING MARGIN (10.00) % MULTIPLIER= (HOURLY RATE+ OVERHEAD+ FRINGE+ OPERATING MARGIN)/ HOURLY RATE Note: *Maximum Billing Rates will not exceed $250.00/HR. BCF #202_CS (Rev. 07.01.2018) RFP Contract #PNC2119168P1 Page 56 of 109 EXHIBIT B MAXIMUM BILLING RATES - HOME OFFICE Contract No: PNC2119168P1 Contract Title: Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering Inc. Subconsultant Name: Keith and Associates, Inc. MAXIMUM TITLE HOURLY RATE ($/HR} Project Manager 2 $89.41 Chief Engineer 1 $80.46 Project Manager 1 $65.79 Subsurface Utility Location Manager 1 $65.79 SUR Chief Surveyor $62.92 Engineer 2 $62.73 Senior Planner $60.20 Chief Utility Coordinator $59.98 Senior Landscape Architect $57.82 SUR Senior Surveyor $55.50 Senior Designer $49.45 Senior Utility Coordinator $49.22 Engineer 1 $48.21 Landscape Architect $41.65 SUR Surveyor $40.87 Utility Coordinator $35.70 Engineering Intern $34.96 Subsurface Utility Field Crew Supervisor I $34.41 Planner $33.61 CADD/Computer Technician $31.97 Multiplier of 2.42 is calculated as follows: OVERHEAD= FRINGE= HOURLY RATE X OVERHEAD (85.38) % HOURLY RATE X FRINGE (35.05) % MAXIMUM MULTIPLIER BILLING RATE X 2.42 = ($/HR} 2.42 $216.37 2.42 $194.71 2.42 $159.21 2.42 $159.21 2.42 $152.27 2.42 $151.81 2.42 $145.68 2.42 $145.15 2.42 $139.92 2.42 $134.31 2.42 $119.67 2.42 $119.11 2.42 $116.67 2.42 $100.79 2.42 $98.91 2.42 $86.39 2.42 $84.60 2.42 $83.27 2.42 $81.34 2.42 $77.37 OPERATING MARGIN= (HOURLY RATE+ OVERHEAD+ FRINGE) X OPERATING MARGIN (10.00) % MULTIPLIER= (HOURLY RATE+ OVERHEAD+ FRINGE+ OPERATING MARGIN)/ HOURLY RATE BCF #202_CS (Rev 07 01 .2018) RFF' Contract #PNC2119168P1 Page 57 of 109 EXHIBIT B-1 MAXIMUM BILLING RATES - FIELD OFFICE Contract No: PNC2119168Pl Contract Title: Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering Inc. Subconsultant Name: Keith and Associates, Inc. MULTIPLIER MAXIMUM MAXIMUM BILLING TITLE HOURLY RATE RATE ($/HR} X 2.15 = ($/HR} CEI Senior Project Engineer $73.58 2.15 $158.20 CEI Project Administrator/CE! Project Engineer $50.52 2.15 $108.62 CEI Senior Inspector/Senior Engineer Intern $35.10 2.15 $75.47 CEI Secretary/Clerical $27.00 2.15 $58.05 CEI Inspector/Engineer Intern $26.25 2.15 $56.44 Multiplier of 2.15 is calculated as follows: OVERHEAD= HOURLY RATE X OVERHEAD (60.76) % FRINGE= HOURLY RATE X FRINGE (35.05) % OPERATING MARGIN= (HOURLY RATE+ OVERHEAD+ FRINGE) X OPERATING MARGIN (10.00) % MULTIPLIER= (HOURLY RATE+ OVERHEAD+ FRINGE+ OPERATING MARGIN)/ HOURLY RATE DIRECT EXPENSE RATE= 0.00% BCF #202_CS (Rev 07.01.2018) RFP Contract #PNC2119168P1 Page 58 of 109 EXHIBIT B-2 REIMBURSABLES Contract No: PNC2119168Pl Contract Title: Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering Inc. Subconsultant Name: Keith and Associates, Inc. UNIT PRICE REIMBURSABLES ITEM UNIT UNIT PRICE Survey Crew - 2 Person Per Crew ($/HR) $130.00 Survey Crew - 3 Person Per Crew ($/HR) $160.00 Survey Crew - 4 Person Per Crew ($/HR) $200.00 Subsurface Designation Per Crew ($/HR) $200.00 Vacuum Excavations Pervious Per Hole/ Each $350.00 Vacuum Excavations Impervious Per Hole/ Each $500.00 Note: The unit prices shown above include all materials, labor, equipment, overhead and profit for the field data collection, evaluation, analysis, and documentation for use in the project deliverables. BCF #202_CS (Rev. 07 01 .2018) RFP Contract #PNC2119168P1 Page 59 of 109 EXHIBIT B MAXIMUM BILLING RATES - HOME OFFICE Contract No: PNC2119168Pl Contract Title: Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering, Inc. Subconsultant Name: Southeastern Archaeological Research, Inc. MAXIMUM MULTIPLIER BILLING RATE MAXIMUM 2.50 HOURLY RATE ($/HR) TITLE ($/HR) X = Project Manager 1 $65.79 2.50 $164.48 Senior Scientist (Architectural Historian) $46.23 2.50 $115.58 Chief Archaeologist $44.57 2.50 $111.43 GIS Specialist $43.30 2.50 $108.25 Senior Archaeologist $32.30 2.50 $80.75 Archaeologist $28.35 2.50 $70.88 Scientist (Historian) $27.28 2.50 $68.20 Secretary/Clerical $27.00 2.50 $67.50 Multiplier of 2.50 is calculated as follows: OVERHEAD= HOURLY RATE X OVERHEAD (71.78) % FRINGE = HOURLY RATE X FRINGE (55.23) % OPERATING MARGIN= (HOURLY RATE+ OVERHEAD+ FRINGE) X OPERATING MARGIN (10.00) % MULTIPLIER= (HOURLY RATE+ OVERHEAD+ FRINGE+ OPERATING MARGIN BCF #202_CS (Rev. 07.01.2018) RFP Contract #PNC2119168P1 Page 60 of 109 EXHIBIT B MAXIMUM BILLING RATES - HOME OFFICE Contract No: PNC2119168Pl Contract Title: Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering Inc. Subconsultant Name: Stoner & Associates, Inc. MAXIMUM MULTIPLIER MAXIMUM TITLE HOURLY 2.52 BILLING RATE RATE ($/HR) X = ($/HR) SUR Chief Surveyor $62.92 2.52 $158.56 SUR Senior Project Surveyor $57.70 2.52 $145.40 SUR Project Surveyor $55.29 2.52 $139.33 SUR Field Crew Supervisor 1 $34.41 2.52 $86.71 CADD/Computer Technician $31.97 2.52 $80.56 SUR Secretary/Clerical $30.57 2.52 $77.04 Multiplier of 2.52 is calculated as follows: OVERHEAD= HOURLY RATE X OVERHEAD (99.33) % FRINGE= HOURLY RATE X FRINGE (30.06) % OPERATING MARGIN= (HOURLY RATE+ OVERHEAD+ FRINGE) X OPERATING MARGIN (10.00) % MULTIPLIER= (HOURLY RATE+ OVERHEAD+ FRINGE+ OPERATING MARGIN)/ HOURLY RATE BCF #202_CS (Rev. 07 01 .2018) RFP Contract #Pf\JC21 i9168P1 Page 61 of 109 EXHIBIT B-2 REIMBURSABLES Project No: PNC2119168Pl Project Title: Consultant/ Subconsultant Name: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering, Inc. Stoner & Associates, Inc. UNIT PRICE REIMBURSABLES ITEM UNIT UNIT PRICE Survey Crew - 3 Person Per Crew ($/HR) $160.00 Note: The unit prices shown above include all materials, labor, equipment, overhead and profit for the field data collection, evaluation, analysis, and documentation for use in the project deliverables. BCF #202_CS (Rev. 07.01.2018) RFP Contract #PNC2119168P1 Page 62 of 1 09 EXHIBIT B MAXIMUM BILLING RATES - HOME OFFICE Contract No: PNC2119168Pl Contract Title: Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering, Inc. Subconsultant Name: Tierra South Florida, Inc. MAXIMUM MULTIPLIER MAXIMUM HOURLY RATE 3.00 BILLING RATE TITLE ($/HR} X = ($/HR} Project Manager 3 $91.35 3.00 $250.00* Chief Engineer 1 $80.46 3.00 $241.38 Senior Engineer 2 $79.80 3.00 $239.40 Chief Scientist $71.00 3.00 $213.00 Project Manager 1 $65.79 3.00 $197.37 Engineer 1 $48.21 3.00 $144.63 Utility Coordinator $35.70 3.00 $107.10 Senior Engineering Technician $34.00 3.00 $102.00 Engineering Technician $27.89 3.00 $83.67 Secretary/Clerical $27.00 3.00 $81.00 Contract Coordinator $24.50 3.00 $73.50 Multiplier of 3.00 is calculated as follows: OVERHEAD= HOURLY RATE X OVERHEAD (120.82) % FRINGE= HOURLY RATE X FRINGE (51.91) % OPERATING MARGIN= (HOURLY RATE+ OVERHEAD+ FRINGE) X OPERATING MARGIN (10.00) % MULTIPLIER= (HOURLY RATE+ OVERHEAD+ FRINGE+ OPERATING MARGIN)/ HOURLY RATE Note: *Maximum Billing Rates will not exceed $250.00/HR. BCF #202_CS (Rev. 07.01 2018) RFP Contract #PNC2119168P1 Page 63 of 109 EXHIBIT B-1 MAXIMUM BILLING RATES - FIELD OFFICE Contract No: PNC2119168Pl Contract Title: Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering, Inc. Subconsultant Name: Tierra South Florida, Inc. MAXIMUM MAXIMUM MULTIPLIER BILLING HOURLY RATE RATE 2.31 TITLE ($/HR} X = ($/HR) CEI Senior Inspector/Senior Engineer Intern $35.10 2.31 $81.08 CEI Asphalt Plant Inspector $29.50 2.31 $68.15 CEI Inspector/Engineer Intern $26.25 2.31 $60.64 Multiplier of 2.31 is calculated as follows: OVERHEAD= HOURLY RATE X OVERHEAD (110.00) % FRINGE= HOURLY RATE X FRINGE (0.00) % OPERATING MARGIN= (HOURLY RATE+ OVERHEAD+ FRINGE) X OPERATING MARGIN (10.00) % MULTIPLIER= (HOURLY RATE+ OVERHEAD+ FRINGE+ OPERATING MARGIN)/ HOURLY RATE Notes: Subconsultant has elected to use "Safe Harbor" combined fringe benefit and overhead rate of 110% in accordance with

2.5. FIELD OFFICE DIRECT EXPENSE RATE= 0.00% BCF #202_ CS (Rev. 07.01.2018) RFP Contract #PNC2119168P1 Page 64 of 109 EXHIBIT B MAXIMUM BILLING RATES - HOME OFFICE Contract No: PNC2119168P1 Contract Title: Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering, Inc. Subconsultant Name: TranSystems Corporation MAXIMUM MULTIPLIER BILLING MAXIMUM 2.74 RATE HOURLY RATE TITLE ($/HR) X = ($/HR) Project Manager 3 $91.35 2.74 $250.00* Senior Engineer 2 $79.80 2.74 $218.65 Senior Electrical Engineer $74.55 2.74 $204.27 Senior Engineer 1 $71.60 2.74 $196.18 Senior Mechanical Engineer $69.27 2.74 $189.80 Engineer 2 $62.73 2.74 $171.88 Engineer 1 $48.21 2.74 $132.10 Electrical Engineer $46.36 2.74 $127.03 Mechanical Engineer $45.43 2.74 $124.48 Senior Certified Bridge Inspector $36.93 2.74 $101.19 Engineering Intern $34.96 2.74 $95.79 Senior Engineering Technician $34.00 2.74 $93.16 Secretary/Cle ri ca I $27.00 2.74 $73.98 Assistant Bridge Inspector $26.84 2.74 $73.54 Multiplier of 2.74 is calculated as follows: OVERHEAD= HOURLY RATE X OVERHEAD (96.29) % includes fringe FRINGE= HOURLY RATE X FRINGE (53.18) % OPERATING MARGIN= (HOURLY RATE+ OVERHEAD+ FRINGE) X OPERATING MARGIN (10.00) % MULTIPLIER= (HOURLY RATE+ OVERHEAD+ FRINGE+ OPERATING MARGIN)/ HOURLY RATE Note: *Maximum Billing Rates will not exceed $250.00/HR. BCF #202_CS (Rev. 07.01.2018) RFP Contract #PNC2119168P1 Page 65 of 109 EXHIBIT B MAXIMUM BILLING RATES - HOME OFFICE Contract No: PNC2119168Pl Contract Title: Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering, Inc. Subconsultant Name: Wantman Group, Inc. MAXIMUM MAXIMUM MULTIPLIER BILLING HOURLY RATE 3.00 RATE {$/HR) TITLE X = {$/HR) Chief Engineer 2 $92.67 3.00 $250.00* Chief Planner $89.84 3.00 $250.00* Senior Engineer 2 $79.80 3.00 $239.40 Senior Engineer 1 $71.60 3.00 $214.80 Engineer 2 $62.73 3.00 $188.19 Senior Planner $60.20 3.00 $180.60 Senior Landscape Architect $57.82 3.00 $173.46 SUR Senior Surveyor $55.50 3.00 $166.50 SUR Project Surveyor $55.29 3.00 $165.87 Engineer 1 $48.21 3.00 $144.63 GIS Specialist $43.30 3.00 $129.90 Project Planner $39.99 3.00 $119.97 SUR Survey/GIS/SUE Analyst 3 Senior $36.88 3.00 $110.64 Engineering Intern $34.96 3.00 $104.88 SUR Secretary/ Clerical $30.57 3.00 $91.71 SUR Survey/GIS/SUE Analyst 2 Junior $25.69 3.00 $77.07 SUR Survey/GIS/SUE Analyst 1 Entry $19.38 3.00 $58.14 Multiplier of 3.00 is calculated as follows: OVERHEAD= HOURLY RATE X OVERHEAD (121.47) % FRINGE= HOURLY RATE X FRINGE (51.26) % OPERATING MARGIN= (HOURLY RATE+ OVERHEAD+ FRINGE) X (10.00) % MULTIPLIER= (HOURLY RATE+ OVERHEAD+ FRINGE+ OPERATING MARGIN)/ HOURLY RATE Note: *Maximum Billing Rates will not exceed $250.00/HR. BCF #202_CS (Rev 07.01.2018) RFP Contract#PNC2119168P1 Page 66 of 109 EXHIBIT B-2 REIMBURSABLES Project No: PNC2119168Pl Project Title: Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering, Inc. Subconsultant Name: Wantman Group, Inc. UNIT PRICE REIMBURSABLES ITEM UNIT UNIT PRICE Survey Crew - 2 Person Per Crew ($/HR) $130.00 Survey Crew - 3 Person Per Crew ($/HR) $160.00 Survey Crew - 4 Person Per Crew ($/HR) $200.00 Subsurface Designation Per Crew ($/HR) $200.00 Vacuum Excavations Pervious Per Hole/Each $350.00 Vacuum Excavations Impervious Per Hole/Each $500.00 Note: The unit prices shown above include all materials, labor, equipment, overhead and profit for the field data collection, evaluation, analysis, and documentation for use in the project deliverables. BCF #202_ CS (Rev 07.01.2018) RFF' Conti-act #PNC2119168P1 Page 67 of 1 09 Contract No: PNC2119168P1 EXHIBIT B-3 TESTING LOADED RATES Contract Title: Continuing Engineering Services for Taffic, Roadway, and Civil Projects Consultant: Metric Engineering, Inc. Subconsultants: HP Consultants, Inc. FOOT Name / Pay Item 401-Geo Auger Borings-H& & Truck/Mud Bug 402-Geo Auger Borings-Track 404-Geo Backhoe (Rental without labor) 406-Geo Barge (Rental without labor) 408-Geo Concrete Pad & Cover for Monitoring Wells 415-Geo Double Ring Infiltration ASTM D3385 417-Geo Dozer (Rental without labor) 418-Geo Drill Crew Support Vehicle 422-Geo Extra SPT Samples-Barge/Track/Amphib 0-50 Ft 423-Geo Extra SPT Samples-Barge/Track/Amphib 50-100 Ft 424-Geo Extra SPT Samples-Barge/Track/Amphib 100-150 Ft 425-Geo Extra SPT Samples-Barge/Track/Amphib 150-200 Ft 426-Geo Extra SPT Samples-Barge/Track/Amphib 200-250 Ft 427-Geo Extra SPT Samples-Truck/Mud Bug 0-50 Ft 428-Geo Extra SPT Samples-Truck/Mud Bug 50-100 Ft 429-Geo Extra SPT Samples-Truck/Mud Bug 100-150 Ft 430-Geo Extra SPT Samples-Truck/Mud Bug 150-200 Ft 431-Geo Extra SPT Samples-Truck/Mud Bug 200-250 Ft 432-Geo Field Perm 0-1 0 Ft Open-End Borehole Method 433-Geo Field Perm 10-25Ft Open-End Borehole Method 435-Geo Grout Boreholes- Barge/Track/Amphib 0-50 Ft 436-Geo Grout Boreholes- Barge/Track/Amphib 50-100 Ft 437-Geo Grout Boreholes- Barge/Track/Amphib 100-150 Ft 438-Geo Grout Boreholes- Barge/Track/Amphib 150-200 Ft 439-Geo Grout Boreholes- Barge/Track/Amphib 200-250 Ft 440-Geo Grout Boreholes- Truck/Mud Bug 0-50 Ft 441-Geo Grout Boreholes-Truck/Mud Bug 50-100 Ft 442-Geo Grout Boreholes- Truck/Mud Bug 100-150 Ft 443-Geo Grout Boreholes- Truck/Mud Bug 150-200 Ft 444-Geo Grout Boreholes- Truck/Mud Bug 200-250 Ft 445-Geo Grouted Monitor Well 2in 0-50 Ft 452-Geo Rock Coring Brg/Track/Amph 0-50 Ft 4in ID & over 453-GeoRocCoring Brg/Track/Amp 0-50 Ft les than 4in ID 454-GeoRocCoring Brg/Track/Amph 50-100 Ft 4in ID & over 455-GeoRocCoring Brg/Track/Amp 50-1 00Ft les than 4in ID 456-GeoRocCoring Brg/Track/Amph 100-150 Ft 4in ID &_over -------------- 457-GeoRocCoring Brg/Track/Amp 100-150Ft les than 4in ID 458-GeoRocCoring Brg/Track/Amph 150-200 Ft 4in ID & over 459-GeoRocCoring Brg/Track/Amp 150-200Ft les than 4in ID 460-GeoRocCoring Brg/Track/Amph 200-250 Ft 4in ID & over 461-GeoRocCoring Brg/Track/Amp 200-250Ft les than 4in ID 462-Geo Rock Coring Truck/Mud Bug 0-50 Ft 4in ID & over 463-GeoRocCoring Truck/MudBug 0-50 Ft less than 4in ID 464-Geo Rock Coring Truck/Mud Bug 50-100 Ft 4in ID over 465-GeoRocCoring Truck/MudBug 50-100 Ft les than 4in ID 466-GeoRocCoring Truck/Mud Bug 100-150 Ft 4in ID & over BCF #202_CS (f,ev. 07 01 .2018) RFP Contract #PNC2119168F'1 Loaded Rate $ 9.92 $ 11.85 $ 379.14 $ 4,652.58 $ 249.81 $ 433.30 $ 846.56 $ 149.89 $ 42.27 $ 48.74 $ 57.81 $ 73.68 $ 102.16 $ 34.86 $ 39.63 $ 44.88 $ 50.22 $ 64.86 $ 314.81 $ 359.00 $ 6.70 $ 7.94 $ 8.69 $ 12.00 $ 13.85 $ 4.89 $ 5.84 $ 7.20 $ 8.70 $ 9.78 $ 21.50 $ 55.45 $ 43.00 $ 66.67 $ 50.00 $ 75.00 $ 60.00 $ 90.85 $ 75.00 $ 107.68 $ 93.75 $ 45.24 $ 38.04 -- - . $ 53.89 $ 42.64 $ 60.00 Unit LF LF Task Task Each Each Task Day Each Each Each Each Each Each Each Each Each Each Each Each LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF -- LF LF LF LF LF LF LF LF LF LF Page G8 of 109 Contract No: PNC2119168P1 EXHIBIT B-3 TESTING LOADED RATES Contract Title: Continuing Engineering Services for Taffic, Roadway, and Civil Projects Consultant: Metric Engineering, Inc. Subconsultants: HP Consultants, Inc. FOOT Name / Pay Item 467-GeoRocCoring Truck/MudBug 100-150 Ft les than 4in ID 468-GeoRocCoring Truck/Mud Bug 150-200 Ft 4in ID & over 469-GeoRocCoring Truck/MudBug 150-200 Ft les than 4in ID 470-GeoRocCoring Truck/Mud Bug 200-250 Ft 4in ID & over 471-GeoRocCoring Truck/MudBug 200-250 Ft les than 4in ID 473-Geo SPT Barge/Track/Amphib 0-50 Ft 474-Geo SPT Barge/Track/Amphib 50-100 Ft 475-Geo SPT Barge/Track/Amphib 100-150 Ft 476-Geo SPT Barge/Track/Amphib 150-200 Ft 477-Geo SPT Barge/Track/Amphib 200-250 Ft 478-Geo SPT Truck/Mud Bug 0-50 Ft 479-Geo SPT Truck/Mud Bug 50-100 Ft 480-Geo SPT Truck/Mud Bug 100-150 Ft 481-Geo SPT Truck/Mud Bug 150-200 Ft 482-Geo SPT Truck/Mud Bug 200-250 Ft 483-Geo Temp Casing 3in Barge/Track/Amphib 0-50 Ft 484-Geo Temp Casing 3in Barge/Track/Amphib 50-100 Ft 485-Geo Temp Casing 3in Barge/Track/Amphib 100-150 Ft 486-Geo Temp Casing 3in Barge/Track/Amphib 150-200 Ft 487-Geo Temp Casing 3in Barge/Track/Amphib 200-250 Ft 488-Geo Temp Casing 3in Truck/Mud Bug 0-50 Ft 489-Geo Temp Casing 3in Truck/Mud Bug 50-100 Ft 490-Geo Temp Casing 3in Truck/Mud Bug 100-150 Ft 491-Geo Temp Casing 3in Truck/Mud Bug 150-200 Ft 492-Geo Temp Casing 3in Truck/Mud Bug 200-250 Ft 493-Geo Temp Casing 4in Barge/Track/Amphib 0-50 Ft 494-Geo Temp Casing 4in Barge/Track/Amphib 50-100 Ft 495-Geo Temp Casing 4in Barge/Track/Amphib 100-150 Ft 496-Geo Temp Casing 4in Barge/Track/Amphib 150-200 Ft 497-Geo Temp Casing 4in Barge/Track/Amphib 200-250 Ft 498-Geo Temp Casing 4in Truck/Mud Bug 0-50 Ft 499-Geo Temp Casing 4in Truck/Mud Bug 50-100 Ft 500-Geo Temp Casing 4in Truck/Mud Bug 100-150 Ft 501-Geo Temp Casing 4in Truck/Mud Bug 150-200 Ft 502-Geo Temp Casing 4in Truck/Mud Bug 200-250 Ft 503_~~0 Temp Casing_~~~ Barge/Trac_~/~rr_i_phi_!)~_.?_0_~~-00_!"! ___ 504-Geo Temp Casing 6in Barge/Track/Amphib 200-250 Ft 505-Geo Temp Casing 6in Barge/Track/Amphib 0-50 Ft 506-Geo Temp Casing 6in Barge/Track/Amphib 50-100 Ft 507-Geo Temp Casing 6in Barge/Track/Amphib 100-150 Ft 508-Geo Temp Casing 6in Truck/Mud Bug 0-50 Ft 509-Geo Temp Casing 6in Truck/Mud Bug 50-100 Ft 510-Geo Temp Casing 6in Truck/Mud Bug 100-150 Ft 511-Geo Temp Casing 6in Truck/Mud Bug 150-200 Ft 512-Geo Temp Casing 6in Truck/Mud Bug 200-250 Ft 514-Geo Truck/Mud Bug Mobil (30 miles straightline distance) UCF #202_ CS (Rev 07.01.2018) 1,1°1--' Contract #PNC2119168P1 Loaded Rate $ 50.56 $ 70.04 $ 53.22 $ 81.98 $ 60.96 $ 16.74 $ 20.06 $ 27.49 $ 30.00 $ 56.77 $ 13.38 $ 15.35 $ 21.54 $ 24.33 $ 32.84 $ 8.75 $ 11.00 $ 12.17 $ 19.00 $ 27.19 $ 7.15 $ 7.85 $ 8.82 $ 9.33 $ 17.32 $ 13.47 $ 15.39 $ 17.55 $ 20.65 $ 26.02 $ 8.96 $ 10.65 $ 12.53 $ 13.90 $ 17.74 $ 28.61 ---------- ·----- $ 33.79 $ 15.00 $ 17.00 $ 19.25 $ 11.77 $ 13.79 $ 16.21 .... $ 21.54 $ 25.40 $ 411.33 Unit LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF -------·--- --------------- . -- -- ·-- LF LF LF LF LF LF LF LF LF Each rage 69 of 109 Contract No: PNC2119168P1 EXHIBIT B-3 TESTING LOADED RATES Contract Title: Continuing Engineering Services for Taffic, Roadway, and Civil Projects Consultant: Metric Engineering, Inc. Subconsultants: HP Consultants, Inc. FOOT Name I Pay Item 515-Geo Undisturbed Samples Barge/Track/Amphib 0-50 Ft 516-Geo Undisturbed Samples Barge/Track/Amphib 50-100Ft 517-Geo Undisturbed Samples Brg/Track/Amph 100-150 Ft 518-Geo Undisturbed Samples Brg/Track/Amph 150-200 Ft 519-Geo Undisturbed Samples Truck/Mud Bug 0-50 Ft 520-Geo Undisturbed Samples Truck/Mud Bug 50-100 Ft 521-Geo Undisturbed Samples Truck/Mud Bug 100-150 Ft 522-Geo Undisturbed Samples Truck/Mud Bug 150-200 Ft 525-Geo Well Development 531-Geo Truck/Mudbug Drill Rig and Crew (2-person) 532-Geo Truck/Mudbug Drill Rig and Crew (3-person) 533-Geo Track/Barge Drill Rig and Crew (2-person) 534-Geo Track/Barge Drill Rig and Crew (3-person) 603-Mobilization Asphalt Coring Equipment 609-Mobilization Drill Rig Barge Mount 610-Mobilization Drill Rig Track Mount 611-Mobilization Drill Rig Trailer Mount 612-Mobilization Drill Rig Truck Mount 614-Mobilization Mudbug/AII Terrain Vehicle 618-Mobilization Support Boat 619-Mobilization Tri-Pod 620-Mobilization of Clearing Equipment 700-MOT Arrow Board 701-MOT Attenuator Truck 702-MOT Channelizing Devices - Type I, II, VP, Drum (each) 703-MOT Light Tower 704-MOT Portable Changeable Message Sign (PCMS) 705-MOT Portable Lighting 706-MOT Portable Sign 707-MOT Post Mounted Sign 708-MOT Provide Channelizing Devices - Cone 709-MOT Radar Speed Display Unit (RDSU) 710-MOT Shadow Vhcle w/ Adv. Warning Arrow & Attenuator 711-MOT Shadow Vhcle w/ Advanced Warning Arrow Board (AWA) 712-MOT Support Vehicle 800-Soils Chloride Soil or Water FM 5-552 ------·------------ --------- ·---·- ------·----------------·----- - ---- -·----·----- 805-Soils Corrosion Series FM 5-550 through 5-553 809-Soils Hydrometer Only AASHTO T88 810-Soils Limerock Bearing Ratio (LBR) FM 5-515 811-Soils Liquid Limit AASHTO T89 812-Soils Materials Finer than 200 Sieve FM 1-T011 813-Soils Maximum Density ASTM D4254 814-Soils Miniature Vane Shear Test ASTM D4648 815-Soils Minimum Density ASTM D4253 817-Soils Moisture Content Laboratory AASHTO T265 818-Soils Moisture Content Microwave AASHTO D4643 BCI" #202 __ CS (Rev. 07 01 .2018) l~FP Contract #PNC211916BP1 ------·---- - ------ - ·- --·--- Loaded Rate $ 142.02 $ 160.54 $ 174.53 $ 235.77 $ 117.02 $ 130.06 $ 120.00 $ 161.54 $ 130.39 $ 200.00 $ 269.26 $ 250.00 $ 340.30 $ 310.64 $ 6,500.00 $ 1,091.97 $ 410.80 $ 372.81 $ 678.72 $ 402.53 $ 350.00 $ 606.06 $ 31.36 $ 127.34 $ 0.60 $ 138.57 $ 91.74 $ 103.55 $ 3.94 $ 10.00 $ 0.76 $ 23.00 $ 125.00 $ 100.00 $ 44.53 $ 39.89 -- -:r·· ------ 136.09 $ 100.56 $ 310.50 $ 45.53 $ 34.06 $ 165.08 $ 12.51 $ 158.66 $ 11.77 $ 16.50 Unit Each Each Each Each Each Each Each Each Hour Hour Hour Hour Hour Each Each Each Each Each Each Each Each Each Each Hour Each Each Each Each Each Each Each Each Hour Hour Hour Test -·-·----·- --------·--·----- ------ Test Test Test Test Test Test Test Test Test Test Page 70 of 109 Contract No: PNC2119168P1 EXHIBIT B-3 TESTING LOADED RATES Contract Title: Continuing Engineering Services for Taffic, Roadway, and Civil Projects Consultant: Metric Engineering, Inc. Subconsultants: HP Consultants, Inc. FDOT Name / Pay Item 819-Soils Organic Content Ignition FM 1 T-267 820-Soils Organic Content Wet Combustion AASHTO T194 821-Soils Particle Size Anlys AASHTO T88 (Incl. Hydrometer) 822-Soils Particle Size Anlys AASHTO T88 (No Hydrometer) 825-Soils pH Soil or Water FM 5-550 826-Soils Plastic Limit & Plasticity Index AASHTO T90 827-Soils Proctor Modified FM 1-T180 828-Soils Proctor Standard AASHTO T99 829-Soils Resistivity Soil or Water FM 5-551 830-Soils Shrinkage Factor AASHTO T92 831-Soils Specific Gravity AASHTO T100 832-Soils Split Tensile Strgth of Rock Cores ASTM D3967 833-Soils Sulfate Soil or Water FM 5-553 838-Soils Unconfined Compression - Rock ASTM D7012, Method C 839-Soils Unconfined Compress - Soil AASHTO T208/ASTM D2166 RCF #:>02 __ cs (f~ev. 01 01 .201B) Rf-P Contract #PNC2119168P1 Loaded Rate $ 36.16 $ 44.00 $ 86.11 $ 57.08 $ 33.82 $ 45.33 $ 93.33 $ 90.75 $ 42.14 $ 60.00 $ 70.64 $ 99.70 $ 42.55 $ 94.78 $ 111.41 Unit Test Test Test Test Test Test Test Test Test Test Test Test Test Test Test Page 71 of 109 EXHIBIT B-3 TESTING LOADED RA TES Contract No: PNC2119168P1 Contract Title: Continuing Engineering Services for Taffic, Roadway, and Civil Projects Consultant: Metric Engineering, Inc. Subconsultants: Florida Engineering and Testing, Inc. Tierra South Florida, Inc. FOOT Name / Pay Item Loaded Rate Unit 100-Aggregate Acid lnsol Retained 200 Sieve FM 5-510 $ 85.00 Test 101-Aggregate Carbonates & Organic Matter FM 5-514 $ 65.00 Test 102-Aggregate Org. Impurities S& for Concrete AASHTO T21 $ 44.85 Test 103-Aggregate Shell Content of Coarse Aggregate FM 5-555 $ 65.00 Test 104-Aggregate Sieve Anlsys of Fine & Coarse AASHTO T27 $ 43.00 Test 105-Aggregate Soundness AASHTO T104 $ 250.00 Test 106-Aggregate Specific Gravity/Absorption Coarse AASHTO T85 $ 78.00 Test 107-Aggregate Total Moisture Content by Drying AASHTO T255 $ 14.00 Test 108-Aggregate Unit Mass & Voids AASHTO T19 $ 49.74 Test 109-Aggregate Specific Gravity/Absorption Fine AASHTO T84 $ 98.89 Test 200-Asphalt Bulk Specific Gravity FM 1-T166 $ 45.73 Test 201-AsphaltContentFM5-563 $ 119.15 Test 202-Asphalt Friction Panel $ 159.52 Test 203-Asphalt Gradation & Content FM 1-T030 & FM 5-563 $ 181.02 Test 204-Asphalt Gradation FM 1-T030 $ 78.94 Test 205-Asphalt Gyratory Compaction 3 Specimens AASHTO T312 $ 89.71 Test 206-Asphalt Los Angeles (LA) Abrasion Coarse Agg FM 3-C535 $ 296.03 Test 207-Asphalt Los Angeles (LA) Abrasion Small Agg FM 1-T096 $ 305.80 Test 208-Asphalt Max Specific Gravity FM 1-T209 $ 126.39 Test 209-Asphalt Pavement Coring - 4in dia with Base Depth Check $ 121.80 Each 210-Asphalt Pvmt. Coring - 4in dia without Base Depth Check $ 87.00 Each 211-Asphalt Pavement Coring - 6in dia with Base Depth Check $ 110.13 Each 212-Asphalt Pvmnt Coring - 6in dia without Base Depth Check $ 89.15 Each 213-Asphalt Structural Panel (See Long Description) $ 403.87 Test 300-Concrete Beam Flexural Testing ASTM C78 $ 43.17 Test 301-Concrete Compressive Strength of Grout\Mortar ASTM C109 $ 18.50 Test 302-Concrete Cylinder Curing, Capping & Breaking ASTM C39 $ 18.50 Test 303-Concrete Drilled Cores & Sawed Beams ASTM C42 $ 40.00 Test 304-Concrete Masonry Unit Sampling & Testing ASTM C140 $ 95.96 Test 305-Concrete Pavement Coring - 4in Dia $ 122.81 Each 306-Concrete Pavement Coring - 6in Dia $ 157.46 Each 307-Concrete Surface Resistivity AASHTO T358 $ 145.57 Test 400-Geo 3D Thermal Modeling $ 138.11 Hour 401-Geo Auger Borings-H& & Truck/Mud Bug $ 9.92 LF 402-Geo Auger Borings-Track $ 11.85 LF 405-Geo Barge (Owned) $ 2,855.83 Day 406-Geo Barge (Rental without labor) $ 4,652.58 Task 407-Geo Chainsaw (Owned) $ 52.06 Day 408-Geo Concrete Pad & Cover for Monitoring Wells $ 249.81 Each 409-Geo CPT Truck/Mud Bug 0-50 Ft $ 12.63 LF t---------~~-----------------------1-'--------t-------l 410-Geo CPT Truck/Mud BLJg 50~ 100 Ft_ $ __ 13.68 LF 411-Geo CPT Truck/Mud Bug 100-150 Ft $ 15.54 LF 412-Geo CPT Truck/Mud Bug 150-200 Ft $ 17.91 LF 413-Geo Crosshole Sonic Logging (CSL) --------------.. --------------~----- $ 1,455.31 _____ Day __ _ BCF #202 __ CS (Rev 07 01.2018) RFF' Contract #PNC2119168P1 Page 72 of 109 EXHIBIT 8-3 TESTING LOADED RA TES Contract No: PNC2119168P1 Contract Title: Continuing Engineering Services for Taffic, Roadway, and Civil Projects Consultant: Metric Engineering, Inc. Subconsultants: Florida Engineering and Testing, Inc. Tierra South Florida, Inc. FOOT Name / Pay Item Loaded Rate 414-Geo Dilatometer Sounding $ 150.89 415-Geo Double Ring Infiltration ASTM D3385 $ 433.30 416-Geo Dozer (Owned) $ 811.54 417-Geo Dozer (Rental without labor) $ 846.56 418-Geo Drill Crew Support Vehicle $ 149.89 421-Geo Dynamic Pile Testing/Pile Driving Analyzer $ 1,244.45 422-Geo Extra SPT Samples-Barge/Track/Amphib 0-50 Ft $ 42.27 423-Geo Extra SPT Samples-Barge/Track/Amphib 50-100 Ft $ 48.74 424-Geo Extra SPT Samples-Barge/Track/Amphib 100-150 Ft $ 57.81 425-Geo Extra SPT Samples-Barge/Track/Amphib 150-200 Ft $ 73.68 426-Geo Extra SPT Samples-Barge/Track/Amphib 200-250 Ft $ 102.16 427-Geo Extra SPT Samples-Truck/Mud Bug 0-50 Ft $ 34.86 428-Geo Extra SPT Samples-Truck/Mud Bug 50-100 Ft $ 39.63 429-Geo Extra SPT Samples-Truck/Mud Bug 100-150 Ft $ 44.88 430-Geo Extra SPT Samples-Truck/Mud Bug 150-200 Ft $ 50.22 431-Geo Extra SPT Samples-Truck/Mud Bug 200-250 Ft $ 64.86 432-Geo Field Perm 0-10 Ft Open-End Borehole Method $ 314.81 433-Geo Field Perm 10-25Ft Open-End Borehole Method $ 359.00 434-Geo Ground Penetrating Radar (GPR) $ 200.00 435-Geo Grout Boreholes- Barge/Track/Amphib 0-50 Ft $ 6.70 436-Geo Grout Boreholes- Barge/Track/Amphib 50-100 Ft $ 7.94 437-Geo Grout Boreholes- Barge/Track/Amphib 100-150 Ft $ 8.69 438-Geo Grout Boreholes- Barge/Track/Amphib 150-200 Ft $ 12.00 439-Geo Grout Boreholes- Barge/Track/Amphib 200-250 Ft $ 13.85 440-Geo Grout Boreholes- Truck/Mud Bug 0-50 Ft $ 4.89 441-Geo Grout Boreholes- Truck/Mud Bug 50-100 Ft $ 5.84 442-Geo Grout Boreholes- Truck/Mud Bug 100-150 Ft $ 7.20 443-Geo Grout Boreholes- Truck/Mud Bug 150-200 Ft $ 8.70 444-Geo Grout Boreholes- Truck/Mud Bug 200-250 Ft $ 9.78 445-Geo Grouted Monitor Well 2in 0-50 Ft $ 21.50 446-Geo H& Auger with DCP (0-50 ft) ASTM D1452 $ 15.00 447-Geo H& Auger with SCP (0-50 ft) ASTM D1453 $ 15.46 448-Geo Mini Shaft Inspection $ 250.00 449-Geo Noise Monitoring $ 124.20 450-Geo Piezometer 2in 0-50 Ft $ 29.52 45:!_::Geo Pile Integrity Testing $ 223.33 ---------·-·----------·----------. ---··---- ·------•- 452-Geo Rock Coring Brg/Track/Amph 0-50 Ft 4in ID & over $ 55.45 453-GeoRocCoring Brg/Track/Amp 0-50 Ft les than 4in ID $ 43.00 454-GeoRocCoring Brg/Track/Amph 50-100 Ft 4in ID & over $ 66.67 455-GeoRocCoring Brg/Track/Amp 50-100Ft les than 4in ID $ 50.00 456-GeoRocCoring Brg/Track/Amph 100-150 Ft 4in ID & over $ 75.00 457-GeoR9cCoring Brg/Track/Amp 100-150Ft les than 4in ID $ 60.00 -------- - --------·-··-- $ 90.85 4_58-geo~c:.><::~c:.>ri~g B_r(;l(l:ra_ck/J\_rllf'.l0 !~0.~20.0 F_t ~i_n. ID & over -- -- -··- "···-·· -------- --~-- 459-GeoRocCoring Brg/Track/Amp 150-200Ft les than 4in ID 460-GeoRocCoring Brg/Track/Amph 200-250 Ft 4in ID & over 461__-_GeoRocCoring __ ~.!:.9!:r.!:~ck/Amp 200:?.~9£!.!8.~--t~?_n_~Ln.~---------- BCF #202_CS (Rev 07 01 2018) RH., Contract #PNC2119168P 1 $ 75.00 $ 107.68 $ 93.75 -----•-•••us._,.,.--•"•-• Unit Hour Each Day Task Day Dav Each Each Each Each Each Each Each Each Each Each Each Each Hour LF LF LF LF LF LF LF LF LF LF LF LF LF Hour Hour LF ____ Day _____ LF LF LF LF LF LF _______ ,. LF ... LF LF LF ----- --·------- --•~ ---- Page 73 of 109 Contract No: PNC2119168P1 EXHIBIT B-3 TESTING LOADED RA TES Contract Title: Continuing Engineering Services for Taffic, Roadway, and Civil Projects Consultant: Metric Engineering, Inc. Subconsultants: Florida Engineering and Testing, Inc. Tierra South Florida, Inc. FOOT Name/ Pay Item 462-Geo Rock Coring Truck/Mud Bug 0-50 Ft 4in ID & over 463-GeoRocCoring Truck/MudBug 0-50 Ft less than 4in ID 464-Geo Rock Coring Truck/Mud Bug 50-100 Ft 4in ID over 465-GeoRocCoring Truck/MudBug 50-100 Ft les than 4in ID 466-GeoRocCoring Truck/MudBug 100-150 Ft 4in ID & over 467-GeoRocCoring Truck/MudBug 100-150 Ft les than 4in ID 468-GeoRocCoring Truck/MudBug 150-200 Ft 4in ID & over 469-GeoRocCoring Truck/MudBug 150-200 Ft les than 4in ID 470-GeoRocCoring Truck/MudBug 200-250 Ft 4in ID & over 471-GeoRocCoring Truck/MudBug 200-250 Ft les than 4in ID 472-Geo Saximeter Testing 473-Geo SPT Barge/Track/Amphib 0-50 Ft 474-Geo SPT Barge/Track/Amphib 50-100 Ft 475-Geo SPT Barge/Track/Amphib 100-150 Ft 476-Geo SPT Barge/Track/Amphib 150-200 Ft 477-Geo SPT Barge/Track/Amphib 200-250 Ft 478-Geo SPT Truck/Mud Bug 0-50 Ft 479-Geo SPT Truck/Mud Bug 50-100 Ft 480-Geo SPT Truck/Mud Bug 100-150 Ft 481-Geo SPT Truck/Mud Bug 150-200 Ft 482-Geo SPT Truck/Mud Bug 200-250 Ft 483-Geo Temp Casing 3in Barge/Track/Amphib 0-50 Ft 484-Geo Temp Casing 3in Barge/Track/Amphib 50-100 Ft 485-Geo Temp Casing 3in Barge/Track/Amphib 100-150 Ft 486-Geo Temp Casing 3in Barge/Track/Amphib 150-200 Ft 487-Geo Temp Casing 3in Barge/Track/Amphib 200-250 Ft 488-Geo Temp Casing 3in Truck/Mud Bug 0-50 Ft 489-Geo Temp Casing 3in Truck/Mud Bug 50-100 Ft 490-Geo Temp Casing 3in Truck/Mud Bug 100-150 Ft 491-Geo Temp Casing 3in Truck/Mud Bug 150-200 Ft 492-Geo Temp Casing 3in Truck/Mud Bug 200-250 Ft 493-Geo Temp Casing 4in Barge/Track/Amphib 0-50 Ft 494-Geo Temp Casing 4in Barge/Track/Amphib 50-100 Ft 495-Geo Temp Casing 4in Barge/Track/Amphib 100-150 Ft 496-Geo Temp Casing 4in Barge/Track/Amphib 150-200 Ft 497-Geo Temp Casing 4in Barge/Track/Amphib 200-250 Ft 498-Geo Temp Casing 4in Truck/Mud Bug 0-50 Ft · · · · · ------ 499-Geo Temp Casing 4in Truck/Mud Bug 50-100 Ft 500-Geo Temp Casing 4in Truck/Mud Bug 100-150 Ft 501-Geo Temp Casing 4in Truck/Mud Bug 150-200 Ft 502-Geo Temp Casing 4in Truck/Mud Bug 200-250 Ft 503-Geo Temp Casing 6in Barge/Track/Amphib 150-200 Ft 591-~~o I e_rnpg_?~in9 .~Jn ~ar_Q~/Tr~c;~/J\r_npJ1i~ 20_0-?_!_5q_Ft 505-Geo Temp Casing 6in Barge/Track/Amphib 0-50 Ft 506-Geo Temp Casing 6in Barge/Track/Amphib 50-100 Ft 507-Geo Temp Casing 6in Barge/Track/Amphib 100-150_Ft _ BCF #202_CS (Rev. 07.01.2018) RFP Contracl#PNC2119168P1 ------------·---·-·---· --- - ----- -----~··- , _______ -~- ----· Loaded Rate $ 45.24 $ 38.04 $ 53.89 $ 42.64 $ 60.00 $ 50.56 $ 70.04 $ 53.22 $ 81.98 $ 60.96 $ 73.07 $ 16.74 $ 20.06 $ 27.49 $ 30.00 $ 56.77 $ 13.38 $ 15.35 $ 21.54 $ 24.33 $ 32.84 $ 8.75 $ 11.00 $ 12.17 $ 19.00 $ 27.19 $ 7.15 $ 7.85 $ 8.82 $ 9.33 $ 17.32 $ 13.47 $ 15.39 $ 17.55 $ 20.65 $ 26.02 $ 8.96 $ 10.65 $ 12.53 $ 13.90 $ 17.74 $ 28.61 $ 33.79 ----· 15.60 $ $ 17.00 $ 19.25 ---- Unit LF LF LF LF LF LF LF LF LF LF Hour LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF LF -------- LF LF LF LF LF LF -------------·---- LF --·- - LF LF LF __ ,,,._ -·-----·· -••••>- Page 74 of 109 EXHIBIT B-3 TESTING LOADED RA TES Contract No: PNC2119168P1 Contract Title: Continuing Engineering Services for Taffic, Roadway, and Civil Projects Consultant: Metric Engineering, Inc. Subconsultants: Florida Engineering and Testing, Inc. Tierra South Florida, Inc. FOOT Name / Pay Item 508-Geo Temp Casing 6in Truck/Mud Bug 0-50 Ft 509-Geo Temp Casing 6in Truck/Mud Bug 50-100 Ft 510-Geo Temp Casing 6in Truck/Mud Bug 100-150 Ft 511-Geo Temp Casing 6in Truck/Mud Bug 150-200 Ft 512-Geo Temp Casing 6in Truck/Mud Bug 200-250 Ft 513-Geo Thermal Integrity Tester (Tl) 514-Geo Truck/Mud Bug Mobil (30 miles straightline distance) 515-Geo Undisturbed Samples Barge/Track/Amphib 0-50 Ft 516-Geo Undisturbed Samples Barge/Track/Amphib 50-100Ft 517-Geo Undisturbed Samples Brg/Track/Amph 100-150 Ft 518-Geo Undisturbed Samples Brg/Track/Amph 150-200 Ft 519-Geo Undisturbed Samples Truck/Mud Bug 0-50 Ft 520-Geo Undisturbed Samples Truck/Mud Bug 50-100 Ft 521-Geo Undisturbed Samples Truck/Mud Bug 100-150 Ft 522-Geo Undisturbed Samples Truck/Mud Bug 150-200 Ft 523-Geo Vibration & Noise Monitoring 524-Geo Vibration Monitoring 525-Geo Well Development 526-Geo Dynamic Pile Testing/Embedded Data Collector 531-Geo Truck/Mudbug Drill Rig and Crew (2-person) 532-Geo Truck/Mudbug Drill Rig and Crew (3-person) 533-Geo Track/Barge Drill Rig and Crew (2-person) 534-Geo Track/Barge Drill Rig and Crew (3-person) 539-Geo Wash Boring for Rock Cores 0-50 Ft 540-Geo Wash Boring for Rock Cores 50-100 Ft 541-Geo Wash Boring for Rock Cores 100-150 Ft 542-Geo Wash Boring for Rock Cores 150-200 Ft 543-Geo Wash Boring for Rock Cores 200-250 Ft 600-Mobilization - Crosshole Sonic Logging (CSL) Equipment 602-Mobilization - Vibration Monitoring Equipment 603-Mobilization Asphalt Coring Equipment 606-Mobilization Concrete Coring 607-Mobilization Cone Penetrometer Test Rig 608-Mobilization Drill Rig Amphibious 609-Mobilization Drill Rig Barge Mount 610-Mobilization Drill Rig Track Mount ---------· ---~-------- ---- - 611-Mobilization Drill Rig Trailer Mount 612-Mobilization Drill Rig Truck Mount 613-Mobilization Mini-Shaft Inspection Device 614-Mobilization Mudbug/AII Terrain Vehicle 615-Mobilization Pile Driving Analyzer Equipment 616-Mobilization Pile Integrity T~ster Equipment_ _____ -~-,------ 61 ?..-~obilizati~n _!:>_kid f\i9 _ .... -- ·-. -- -- . -- --·-- 618-Mobilization Support Boat 619-Mobilization Tri-Pod 620-Mobilization of Clearing_Equipment -----~---- --••-••• -•-----•~•--M-••- "--•--~- •••-•-•-- --- -'•• --- BCF #?02 __ CS (Rev 07.01 2018) RFF' Contract #PI\JC2119168P1 Loaded Rate Unit $ 11.77 LF $ 13.79 LF $ 16.21 LF $ 21.54 LF $ 25.40 LF $ 223.71 Hour $ 411.33 Each $ 142.02 Each $ 160.54 Each $ 174.53 Each $ 235.77 Each $ 117.02 Each $ 130.06 Each $ 120.00 Each $ 161.54 Each $ 905.51 Day $ 902.62 Day $ 130.39 Hour $ 843.75 Day $ 200.00 Hour $ 269.26 Hour $ 250.00 Hour $ 340.30 Hour $ 10.00 LF $ 11.00 LF $ 13.00 LF $ 15.00 LF $ 13.00 LF $ 233.33 Each $ 209.47 Each $ 310.64 Each $ 309.00 Each $ 891.41 Each $ 7,267.55 Each $ 6,500.00 Each $ 1,091.97 Each -------- $ 410.80 Each $ 372.81 Each $ 1,945.77 Each $ 678.72 Each $ 321.62 Each $ 269.64 Each ·---- ··---------·-·--·· $ 612.70 Each ····-- ------- . ------·-·-·---- . ·- ·-"·•-- $ 402.53 Each $ 350.00 Each $ 60606 Each ---· -" ---------·- -·~- --- Page 75 of 1 OS Contract No: PNC2119168P1 EXHIBIT 8-3 TESTING LOADED RA TES Contract Title: Continuing Engineering Services for Taffic, Roadway, and Civil Projects Consultant: Metric Engineering, Inc. Subconsultants: Florida Engineering and Testing, Inc. Tierra South Florida, Inc. FOOT Name I Pay Item Loaded Rate 700-MOT Arrow Board $ 31.36 701-MOT Attenuator Truck $ 127.34 702-MOT Channelizing Devices - Type I, II, VP, Drum (each) $ 0.60 703-MOT Light Tower $ 138.57 704-MOT Portable Changeable Message Sign (PCMS) $ 91.74 705-MOT Portable Lighting $ 103.55 706-MOT Portable Sign $ 3.94 707-MOT Post Mounted Sign $ 10.00 708-MOT Provide Channelizing Devices - Cone $ 0.76 709-MOT Radar Speed Display Unit (ROSU) $ 23.00 710-MOT Shadow Vhcle w/ Adv. Warning Arrow & Attenuator $ 125.00 711-MOT Shadow Vhcle w/ Advanced Warning Arrow Board (AWA) $ 100.00 712-MOT Support Vehicle $ 44.53 800-Soils Chloride Soil or Water FM 5-552 $ 39.89 801-Soils Consol-Addtl lncrmnts AASHTO T216 (13 to 24 Loads) $ 54.36 802-Soils Consol-Addtl lncrmnts AASHTO T216 (up to 12 Loads) $ 238.33 803-Soils Consolidation - Constant Strain ASTM D4186 $ 489.03 804-Soils Consol-Extend Load lncrmnts AASHTO T216 $ 50.00 805-Soils Corrosion Series FM 5-550 through 5-553 $ 136.09 806-Soils Direct Shear Consolid Drained/ Point FM 3-D3080 $ 175.00 807-Soils Field Vane Shear Test ASTM D2573 $ 133.33 808-Soils Flexible Wall Permeability ASTM D5084 $ 325.00 809-Soils Hydrometer Only AASHTO T88 $ 100.56 810-Soils Limerock Bearing Ratio (LBR) FM 5-515 $ 310.50 811-Soils Liquid Limit AASHTO T89 $ 45.53 812-Soils Materials Finer than 200 Sieve FM 1-T011 $ 34.06 813-Soils Maximum Density ASTM D4254 $ 165.08 814-Soils Miniature Vane Shear Test ASTM D4648 $ 12.51 815-Soils Minimum Density ASTM D4253 $ 158.66 817-Soils Moisture Content Laboratory AASHTO T265 $ 11.77 818-Soils Moisture Content Microwave AASHTO D4643 $ 16.50 819-Soils Organic Content Ignition FM 1 T-267 $ 36.16 820-Soils Organic Content Wet Combustion AASHTO T194 $ 44.00 821-Soils Particle Size Anlys AASHTO T88 (Incl. Hydrometer) $ 86.11 Unit Each Hour Each Each Each Each Each Each Each Each Hour Hour Hour Test Each Each Test Day Test Test Test Test Test Test Test Test Test Test Test Test Test Test Test Test 822-Soils Particle Size Anlys AASHTO T88 (No Hydrometer) $ 57.08 Test 823-Soils Permeability Constant Head AASHTO T_2_15 ______ ··-·--·-----·-·---------··-·•--·-· ....,$$ _____ 2 2 ___ 3 5 8 5 __ ._0 34 0 _________ TT_ee_ss!t _________ _ 824-Soils Permeability Falling Head FM 5-513 825-Soils pH Soil or Water FM 5-550 $ 33.82 Test 826-Soils Plastic Limit & Plasticity Index AASHTO T90 $ 45.33 Test 827-Soils Proctor Modified FM 1-T180 $ 93.33 Test 828-Soils Proctor Standard AASHTO T99 $ 90.75 Test 829-Soils Resistivity Soil or Water FM 5-551 ____ _ ______________________________ ,_$ _____ 4_2_.1_4_1 ______ Tf::_~t ____ _ ~30-_S__c:>~-~ ~~rir1ka9e ~a9t()r_A~~~:_r.9 !,92_ . _ __ _ ........... $ 831-Soils Specific Gravity AASHTO T100 $ 832-Soils Split Tensile Strgth of Rock Cores ASTM D3967 $ BCF #202_ CS (Rev 07 01 .2018) t~FP Contract #PNC2119168P1 6000 70.64 99.70 Test Test Test Page 76 of 109 Contract No: Contract Title: Consultant: Subconsultants: EXHIBIT B-3 TESTING LOADED RA TES PNC2119168P1 Continuing Engineering Services for Taffic, Roadway, and Civil Projects Metric Engineering, Inc. Florida Engineering and Testing, Inc. Tierra South Florida, Inc. FDOT Name / Pay Item Loaded Rate 834-Soils Swell Potential ASTM 04546 835-Soils Triaxl Consl-Drain (CD) Per Point\Cell ASTM 07181 836-Soils Tri Cnsl-Undrn (CU) Pt\Cell AASHTO T297/ASTM 04767 837-Soil Tri Uncsl-Undrn (UU) Pt\Cell AASHTO T296/ASTM 02850 838-Soils Unconfined Compression - Rock ASTM 07012, Method C 839-Soils Unconfined Compress - Soil AASHTO T208/ASTM 02166 BCF #202_ CS (Rev 07 0i 2018) RFP Contract #PNU119168Pi $ 93.36 $ 305.49 $ 293.98 $ 228.91 $ 94.78 $ 111.41 Unit Test Test Test Test Test Test Page 77 of 109 BCF #202_CS (Rev 07.01 2018) RFP Contract #PNC2119168P1 EXHIBIT C Minimum Insurance Requirements Page 78 of 109 INSURANCE REQUIREMENTS Project: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Agency: Highway Construction and Engineering Division GENERAL LlABILITY - Broad form 0 Commercial General Liability 0 Premises-Operations □ XCU Explosion/Collapse/Underground 0 Products/Completed Operations Hazard 0 Contractual Insurance 0 Broad Form Property Damage 0 Independent Contractors 0 Personal Injury Per Occurrence or Claims-Made: 0 Per Occurrence □ Claims-Made Gen'I Aggregate Limit Applies per: □ Project □ Policy □ Loe. o Other AlJTO LIABILITY 0 Comprehensive Form 0 Owned 0 Hired 0 Non-owned 0 Any Auto, If applicable Note: May be waived ifno driving will be done in pe1for111ance of services/project. □ EXCESS LIABILITY/ UMBRELLA Per Occurrence or Claims-Made: □ Per Occurrence o Claims-Made Note: May be used to supplement minimum liability coverage requirements. 0 WORKER'S COMPENSATION Note: U.S. Longshoremen & Harbor Workers· Act & Jones Act is required for any activities on or about navi able water. 0 EMPLOYER'S LIABILITY 0 PROFESSIONAL LIABILITY (ERRORS & OMISSIONS) All engineering, surveying and design professionals. □ POLLUTION/ENVIRONMENTAL LIABILITY D Installation floater is required if Builder's Risk or Property are not carried. Note: Coverage must be "All Risk", Completed Value. NIA NIA 0 □ 0 Bodily Injury Property Damage Combined Bodily Injury and Property Damage Personal Injury Products & Completed Operations Bodily Injury (each person) Bodily Injury ( each accident) Property Damage Combined Bodily Injury and Property Damage Each Accident Each Accident If claims-made fonn: Extended Reporting Period of: *Maximum Deductible: If claims-made f<mn: Extended Reporting Period of: *Maximum Deductible: *Maximum Deductible. Contractor is responsible for deductible $1,000,000 $1,000,000 STATUTORY LIMITS $1,000,000 $2,000,000 3 years $100,000 $10,000 $2,000,000 Completed Value Description of Operations: "Broward County·' shall be listed as Certificate Holder and endorsed as an additional insured for liability. except as to Professional Liability County shall be provided 30 days written notice of rnncellation, I() days' notice of cancellation for non-payment. Contractors insurance shall provide primary coverage and shall not 1equi1c contribution from the County, sclf-insura1,cc 01 otlic1 \\'!Se. Any sclf~insurcd rctrntio11 (Sil{) highc1 than the amount permitted in this ;\grc'cmcn! must be declared to and approved by County and may require proof of financial ability to meet losses. Contractor is responsible for all coverage deductibles unless otherwise specified in the agreement. ~i~' ,';' i, j • •"' ': :' ~~~~~~ffl- ,,i & fl• i ij ~)~.,••,, ~ :~l • ,~ _;J:; l~' ~ - ~ i 8 & • -i , ._ ,. ~ fZF"P-CnntracritPNCc119iMP7 . ~ , 'cpoonall@broward.org , : · • CTl"cpounall@broward.org ~ . .· .. 2019.07.ll HOHJ-04'00' ·· . Page-79 of 1 09 Risk l\1a11ar,cnwn1 ni,·i<-:1n1: BCF #202_CS (Rev. 07.01 2018) RFP Contract #PNC2119168P1 EXHIBIT D Work Authorization Forms Page 80 of 109 (Sample - Contract Administrator Approval Level) EXHIBIT D-1 Work Authorization No. ___ _ Under Agreement between Broward County and ______ _ for 1. This Work Authorization is issued under the Agreement between Broward County ("County") and ______ ("Consultant") for Consultant Services for Continuing Engineering Services for Traffic, Roadway, and Civil Engineering Projects (the "Agreement"), which was approved by the Board of County Commissioners on _____ (Item ). 2. This Work Authorization permits Consultant to provide the services described in Exhibit A to this Work Authorization. 3. Compensation and Method of Payment. 3.1 Payment for the services authorized or approved by this Work Authorization will be in accordance with Article 4 of the Agreement and the agreed method of compensation is as follows (check those boxes that apply): D 3.1.1 Maximum Amount Not-To-Exceed Compensation. For Basic Services identified in Exhibit A to this Work Authorization as payable on a "Maximum Amount Not-To-Exceed" basis, compensation to Consultant shall be based upon the Salary Costs as described in

2 of the Agreement up to a maximum not-to-exceed amount of$ ------ D 3.1.2 Lump Sum Compensation. For Basic Services identified in Exhibit A to this Work Authorization as payable on a "Lump Sum" basis, compensation to Consultant shall be not more than a total lump sum of$ ____ _ D 3.1.3 Reimbursable Expenses. County will reimburse authorized Reimbursable Expenses as defined in

3 of the Agreement up to a maximum not-to- exceed amount of $ _____ . Unused amounts of those monies shall be retained by County. 3.2 Payments for this Work Authorization will be charged against: Budget No. ________________________ _ 4. Consultant shall perform the services described in Exhibit A within: D _______ calendar days ("Time for Performance"), or BCF #202_CS (Rev 07.01.2018) RFP Contract#PNC2119168P1 Page 81 of 109 D the time periods specified in the Project Schedule included in Exhibit A to this Work Authorization {"Time for Performance"); said time periods shall commence from the date of the Notice to Proceed for such services. D 4.1 If this box is checked, this paragraph is applicable. If Contractor fails to □ substantially complete the project on or before the substantial completion date specified in its agreement with County, and the failure to substantially complete is caused in whole or in part by Consultant, then Consultant shall pay to County its proportional share of any claim for damages to Contractor arising out of the delay. The provisions for the computation of delay costs, damages, or any other amounts, whether direct or indirect, in the agreement between the Contractor and County are incorporated herein. This section shall not affect the indemnification rights or obligations of either party otherwise set forth in this Agreement. 4.2 If this box is checked, liquidated damages are applicable. If Consultant fails to complete the services identified in Exhibit A to this Work Authorization on or before the Time for Performance set forth above, then Consultant shall pay to County the sum of dollars identified below for each calendar day after the applicable Time for Performance, plus approved time extensions thereof, until completion of the services: Services Amount $ TBD $ TBD $TBD These amounts are not penalties but are liquidated damages to County for Consultant's inability to prosecute, and complete, the services in a timely manner pursuant to the agreed upon Project Schedule. Liquidated damages are hereby fixed and agreed upon by the Parties, recognizing the impossibility of precisely ascertaining the amount of damages that will be sustained by County as a consequence of such delay, and both parties desiring to obviate any question or dispute concerning the amount of said damages, and the cost and effect of the failure of Consultant to complete the services within the applicable Time for Performance. This section shall not affect the indemnification rights or obligations of either party otherwise set forth in the Agreement. 5. CBE Goals. 5.1 In an effort to assist County in achieving its overall goal as set forth in the Agreement, Consultant agrees to meet the following CBE participation goals by utilizing the CBE firms for the work and dollar values described in paragraph 5.2 below: ________ %. 5.2 In performing services for this Work Authorization, County and Consultant hereby incorporate Consultant's participating CBE firms, addresses, scope of work, and dollar value identified in the Letter of Intent {Exhibit C of this Work Authorization). BCF #202_CS (Rev. 07.01 2018) RFP Contract #PNC2119168P1 Page 82 of 109 6. The terms and conditions of the Agreement are hereby incorporated into this Work Authorization. Nothing contained in this Work Authorization shall alter, modify, or change in any way the terms and conditions of the Agreement with the County. [Remainder of This Page Is Intentionally Left Blank.] BCF #202_CS (Rev 07.01.2018) RFP Contrnct #PNC2119168P1 Page 83 of 109 IN WITNESS WHEREOF, the parties have made and executed this Work Authorization No. __ : BROWARD COUNTY, by and through its Contract Administrator, as authorized pursuant to the Agreement, and --------~ signing by and through its ------------J duly authorized to execute same. WITNESS: Witness Witness ATTEST: Corporate Secretary (SEAL) BCF #202_CS (Rev. 07.01.2018) FffP Contract #PNC2119168P1 County BROWARD COUNTY, by and through its Contract Administrator By ____________ _ __ day of _____ ~ 20_ Consultant [Insert Corporate Name] By ____________ _ President or Vice President (Print Name and Title) __ day of _____ ~ 20_. Page 84 of 109 (Sample - Director of Purchasing Approval Level) EXHIBIT D-2 Work Authorization No. ---- Under Agreement between Broward County and ______ _ for 1. This Work Authorization is issued under the Agreement between Broward County ("County") and ______ ("Consultant") for Consultant Services for Continuing Engineering Services for Traffic, Roadway, and Civil Engineering Projects (the "Agreement"), which was approved by the Board of County Commissioners on _____ (Item ). 2. This Work Authorization permits Consultant to provide the services described in Exhibit A to this Work Authorization. 3. Compensation and Method of Payment. 3.1 Payment for the services authorized or approved by this Work Authorization will be in accordance with Article 4 of the Agreement and the agreed method of compensation is as follows (check those boxes that apply): D 3.1.1 Maximum Amount Not-To-Exceed Compensation. For Basic Services identified in Exhibit A to this Work Authorization as payable on a "Maximum Amount Not-To-Exceed" basis, compensation to Consultant shall be based upon the Salary Costs as described in

2 of the Agreement up to a maximum not-to-exceed amount of$ ------ D 3.1.2 Lump Sum Compensation. For Basic Services identified in Exhibit A to this Work Authorization as payable on a "Lump Sum" basis, compensation to Consultant shall be not more than a total lump sum of$ ----- D 3.1.3 Reimbursable Expenses. County will reimburse authorized Reimbursable Expenses as defined in

3 of the Agreement up to a maximum not-to- exceed amount of $ _____ . Unused amounts of those monies shall be retained by County. 3.2 Payments for this Work Authorization will be charged against: 4. Consultant shall perform the services described in Exhibit A within: D _______ calendar days ("Time for Performance"), or BCF #202 __ cs (Rev. 07.01 2018) RFP Contract #PNC2119168P1 Page 85 of 109 D the time periods specified in the Project Schedule included in Exhibit A to this Work Authorization ("Time for Performance"); said time periods shall commence from the date of the Notice to Proceed for such services. D 4.1 If this box is checked, this paragraph is applicable. If Contractor fails to substantially complete the project on or before the substantial completion date specified in its agreement with County, and the failure to substantially complete is caused in whole or in part by Consultant, then Consultant shall pay to County its proportional share of any claim for damages to Contractor arising out of the delay. The provisions for the computation of delay costs, damages, or any other amounts, whether direct or indirect, in the agreement between the Contractor and County are incorporated herein. This section shall not affect the indemnification rights or obligations of either party otherwise set forth in this Agreement. D 4.2 If this box is checked, liquidated damages are applicable. If Consultant fails to complete the services identified in Exhibit A to this Work Authorization on or before the Time for Performance set forth above, then Consultant shall pay to County the sum of dollars identified below for each calendar day after the applicable Time for Performance, plus approved time extensions thereof, until completion of the services: Services Amount $ TBD $ TBD $TBD These amounts are not penalties but are liquidated damages to County for Consultant's inability to prosecute, and complete, the services in a timely manner pursuant to the agreed upon Project Schedule. Liquidated damages are hereby fixed and agreed upon by the parties, recognizing the impossibility of precisely ascertaining the amount of damages that will be sustained by County as a consequence of such delay, and both parties desiring to obviate any question or dispute concerning the amount of said damages, and the cost and effect of the failure of Consultant to complete the services within the applicable Time for Performance. This section shall not affect the indemnification rights or obligations of either party otherwise set forth in the Agreement. 5. CBE Goals. 5.1 In an effort to assist County in achieving its overall goal as set forth in the Agreement, Consultant agrees to meet the following CBE participation goals by utilizing the CBE firms for the work and dollar values described in paragraph 5.2 below: %. -------- 5.2 In performing services for this Work Authmization, County and Consultant hereby incorporate Consultant's participating CBE firms, addresses, scope of work, and dollar value identified in the Letter of Intent (Exhibit C of this Work Authorization). BCF #202_CS (Rev 07.01 2018) RFP Contract #PNC2119168P1 Page 86 of 109 6. The terms and conditions of the Agreement are hereby incorporated into this Work Authorization. Nothing contained in this Work Authorization shall alter, modify, or change in any way the terms and conditions of the Agreement with the County. [Remainder of This Page Is Intentionally Left Blank.] BCF #202_CS (Rev 07.01.2018) RFP Contr-act #PNC2119168P1 Page 87 of 109 IN WITNESS WHEREOF, the Parties have made and executed this Work Authorization No. __ : BROWARD COUNTY, by and through its Director of Purchasing, as authorized pursuant to the Agreement, and --------~ signing by and through its _________ __, duly authorized to execute same. County WITNESS: BROWARD COUNTY, by and through its Director of Purchasing By ____________ _ Signature of Witness Director Print Name of Witness Signature of Witness Print Name of Witness Contract Administrator ATTEST: Corporate Secretary (SEAL} BCF #202~CS (Rev. 07.01.2018) RFP Contract #PNC2119168P1 Date __ day of _____ _, 20 . Consultant [Insert Corporate Name] By ___________ _ President or Vice President (Print Name and Title} __ dayof _____ _,20 Page 88 of 109 (Sample - County Commission Approval Level) EXHIBIT D-3 Work Authorization No. ___ _ Under Agreement between Broward County and ______ _ for 1. This Work Authorization is issued under the Agreement between Broward County {"County"} and ______ {"Consultant"} for Consultant Services for Continuing Engineering Services for Traffic, Roadway, and Civil Engineering Projects {the "Agreement"}, which was approved by the Board of County Commissioners on _____ {Item }. 2. This Work Authorization permits Consultant to provide the services described in Exhibit A to this Work Authorization. 3. Compensation and Method of Payment. 3.1 Payment for the services authorized or approved by this Work Authorization will be in accordance with Article 4 of the Agreement and the agreed method of compensation is as follows {check those boxes that apply}: D 3.1.1 Maximum Amount Not-To-Exceed Compensation. For Basic Services identified in Exhibit A to this Work Authorization as payable on a "Maximum Amount Not-To-Exceed" basis, compensation to Consultant shall be based upon the Salary Costs as described in

2 of the Agreement up to a maximum not-to-exceed amount of$ ------ D 3.1.2 Lump Sum Compensation. For Basic Services identified in Exhibit A to this Work Authorization as payable on a "Lump Sum" basis, compensation to Consultant shall be not more than a total lump sum of$ ____ _ D 3.1.3 Reimbursable Expenses. County will reimburse authorized Reimbursable Expenses as defined in

3 of the Agreement up to a maximum not-to- exceed amount of $ _____ . Unused amounts of those monies shall be retained by County. 3.2 Payments for this Work Authorization will be charged against: Budget No. _________________________ _ 4. Consultant shall perform the services described in Exhibit A within: D _______ calendar days ("Time for Performance"}, or BCF #202_CS (Rev. 07.01.2018) RFP Contract#PNC2119168P1 Page 89 of 109 D the time periods specified in the Project Schedule included in Exhibit A to this Work Authorization ("Time for Performance"); said time periods shall commence from the date of the Notice to Proceed for such services. D 4.1 If this box is checked, this paragraph is applicable. If Contractor fails to □ substantially complete the project on or before the substantial completion date specified in its agreement with County, and the failure to substantially complete is caused in whole or in part by Consultant, then Consultant shall pay to County its proportional share of any claim for damages to Contractor arising out of the delay. The provisions for the computation of delay costs, damages, or any other amounts, whether direct or indirect, in the agreement between the Contractor and County are incorporated herein. This section shall not affect the indemnification rights or obligations of either party otherwise set forth in this Agreement. 4.2 If this box is checked, liquidated damages are applicable. If Consultant fails to complete the services identified in Exhibit A to this Work Authorization on or before the Time for Performance set forth above, then Consultant shall pay to County the sum of dollars identified below for each calendar day after the applicable Time for Performance, plus approved time extensions thereof, until completion of the services: Services Amount $TBD $TBD $ TBD These amounts are not penalties but are liquidated damages to County for Consultant's inability to prosecute, and complete, the services in a timely manner pursuant to the agreed upon Project Schedule. Liquidated damages are hereby fixed and agreed upon by the Parties, recognizing the impossibility of precisely ascertaining the amount of damages that will be sustained by County as a consequence of such delay, and both parties desiring to obviate any question or dispute concerning the amount of said damages, and the cost and effect of the failure of Consultant to complete the services within the applicable Time for Performance. This section shall not affect the indemnification rights or obligations of either party otherwise set forth in the Agreement. 5. CBE Goals. 5.1 In an effort to assist County in achieving its overall goal as set forth in the Agreement, Consultant agrees to meet the following CBE participation goals by utilizing the CBE firms for the work and dollar values described in paragraph 5.2 below: ________ %. 5.2 In performing services for this Work Authorization, County and Consultant hereby incorporate Consultant's participating CBE firms, addresses, scope of work, and dollar value identified in the Letter of Intent (Exhibit C of this Work Authorization). BCF #202 __ CS (Rev. 07 01 2018) RFP Contract #PNC2119168P1 Page 90 of 109 6. The terms and conditions of the Agreement are hereby incorporated into this Work Authorization. Nothing contained in this Work Authorization shall alter, modify, or change in any way the terms and conditions of the Agreement with the County. [Remainder of This Page Is Intentionally Left Blank.] BCF #202_CS (Rev 07 01 .2018) RFP Contrnct #PNC2119168P1 Page 91 of 109 IN WITNESS WHEREOF, the parties have made and executed this Work Authorization No. BROWARD COUNTY, by and through its BOARD OF COUNTY COMMISSIONERS, signing by and through its Mayor or Vice-Mayor, authorized to execute same by Board action on the __ day of ----~ 20_, and ------~ signing by and through its _________ ...J duly authorized to execute same. ATTEST: Broward County Administrator, as ex officio Clerk of the Broward County Board of County Commissioners Insurance requirements Approved by Broward County Risk Management Division By ___________ _ Signature {Date) Print Name and Title above ATTEST: Corporate Secretary {SEAL) BCF #202_CS (Rev. 07 01 2018) F~FP Contract #PNC2119168P1 County BROWARD COUNTY, by and through its Board of County Commissioners By ___________ _ Mayor __ day of ______ ~ 20 Approved as to form by Andrew J. Meyers Broward County Attorney Governmental Center, Suite 423 115 South Andrews Avenue Fort Lauderdale, Florida 33301 Telephone: {954) 357-7600 Telecopier: {954) 357-7641 By ____________ _ Gavin Rynard {Date) Assistant County Attorney Michael J. Kerr {Date) Deputy County Attorney Consultant [Insert Corporate Name] By ____________ _ President or Vice President {Print Name and Title) __ dayof _____ __,20 Page 92 of 109 The following exhibits shall be incorporated into the Work Authorization: Exhibit A Exhibit B Exhibit C Scope of Services for Work Authorization Payment Schedule for Work Authorization Letters of Intent for Work Authorization BCF #202_CS (Rev 07.01.2018) RFP Contract #PNC2119168P1 Page 93 of 109 EXHIBIT E CBE Subconsultant Schedule and Letters of Intent BCF #202_CS (Rev. 07 01 .2018) RFP Contract #PNC2119168P1 Page 94 of 109 EXHIBIT E Schedule of CBE Subconsultants Project No: PNC2119168Pl Project Title: Prime Consultant: Continuing Engineering Services for Traffic, Roadway, and Civil Projects Metric Engineering, Inc. Firm Name and Address 1. ADEPT Strategy & Public Relations 5300 Powerline Road, Suite 207 Fort Lauderdale, FL 33309 Contact: Julie Ruffolo PH: 954-496-2412 2. BMA Consulting Engineering 18503 Pines Blvd. Suite 210 Pembroke Pines, FL 33029 Contact: Jesus Mustafa PH: 954-744-4691 or 954-483-4786 3. Compass Point Surveyors, PL 3710 Park Central Blvd N Pompano Beach, FL 33064 Contact: Benjamin Wiser PH: 727-919-3358 4. DULAND DESIGN LLC 811 E. Las Olas Blvd., Suite 4 Fort Lauderdale, FL 33301 Contact: Chang Du PH: 954-494-9367 5. EBS Engineering, Inc. 4715 NW 157th Street, Suite# 202 Miami, Florida 33014 Contact: Benjamin Essien PH: 305-625-5252 6. F&J Engineering Group, Inc. 8761 N Lake Dasha Drive, Plantation, FL 33324 Contact: Francis Chin PH: 786-385-2372 BCF #202 __ CS (Rev. 07 01 2018) RFP Contract #PNC2119168P1 Discipline Public relations and Outreach Miscellaneous Structures, Signalization, Drainage Environmental/Permit Support Land Surveying & Mapping Landscape Architecture Roadway Design, Traffic Engineering Studies, Traffic Signal Timing, Intelligent Transportation Systems Analysis and Design, Intelligent Transportation Systems Implementation, Intelligent Transportation Traffic Signing, Pavement Marking and Channelization, Signalization, and Roadway Construction Engineering & Inspection Construction Engineering & Inspection Page 95 of 109 7. Florida Engineering & Testing, Inc. 250 SW 13th Avenue Pompano Beach, FL 33069 Contact: Christine Chang PH: 954-781-6889 8. HP Consultants, Inc. 10220 SW 107th Street Miami, FL 33176 Contact: Arvind Kumbhojkar PH: 305-775-4300 9. Stoner & Associates, Inc. 4341 SW 62 Ave Davie, FL 33314 Contact: Jim Stoner PH: 954-585-0997 or 954-444-9995 BCF #202_CS (Rev 07 01 2018) RFP Contract #fJI\JC2119168P1 Geotechnical Engineering & Investigations, and Construction Materials Testing Geotechnical Engineering & Investigations Land Surveying and Mapping Page 96 of 109 Broward County Board of County Commissioners PNC2119168P1 LETTER OF INTENT BETWEEN BIDDER/OFFEROR AND COUNTY BUSINESS ENTERPRISE (CBE) FIRM/SUPPLIER This form Is to be completed and signed for each CBE firm. tr the PRIME ls a CBE firm, please Indicate the percentage perform Ing with your own forces. Sollcltatlon No}PNC2119168P1 Project Tltle: Continuing Engineering Services for Traffic, Roadway and Civil Projectt3 Blddar/Offeror Name: Metrlo Engineering ----------=------------------------ Address: 525 Technology Park, Suite 153 City: Lake Mary state: FL Zip: 32746 Authorized Representative: Dat~iW. Cody, PE, PTOE Phone: 407-644-1898 CBE Firm/Supplier Name: ADEPT Public Relations, LLC Address: 5300 Powerllne Road, Suite 207 City: Fort Lauderdale state: .!:_ Zip: 33309 Authorized Rapresentatlve: _J_ul_le_R_u_ff_o_lo ______________ Phone: 994-769-1533 A. This Is a letter of Intent between the bidder/offeror on this project and a CBE firm for the CBE to perfom, work on this project. Te>d B. By signing below, the bidder/offerer Is committing to utilize the above-named CBE to perform the work described below. C. By signing below, the above-named CBE Is committing to perform the work described below. D. BY signing below, the bldder/offeror and CBE affirm that If the CBE subcontracts any of the work described below, It may only subcontract that work to another CBE. Work to be performed by CBE Firm Description NAICS 1 CBE Contract CBE Percentage of Amount2 Total Project Value Public Involvement/Outreach 541820 Document Preparation Services 561410 -·- Adm